HomeMy WebLinkAbout00 72 00.pdf"0
L
:; Document A201T" - 2007
General Conditions of the Contract for Construction
for the following PROJECT:
(Name and location or address)
X
THE OWNER:
(Name, legal slams and address)
THE ARCHITECT:
(Name, legal status and address)
TABLE OF ARTICLES
1 GENERAL PROVISIONS
2 OWNER
3 CONTRACTOR
4 ARCHITECT
5 SUBCONTRACTORS
6 CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS
7 CHANGES IN THE WORK
6 TIME
9 PAYMENTS AND COMPLETION
10 PROTECTION OF PERSONS AND PROPERTY
11 INSURANCE AND BONDS
12 UNCOVERING AND CORRECTION OF WORK
13 MISCELLANEOUS PROVISIONS
14 TERMINATION OR SUSPENSION OF THE CONTRACT
15 CLAIMS AND DISPUTES
ADDITIONS AND DELETIONS:
The author of this document has
added information needed for Its
completion. The author may also
have revised the text of the original
AIA standard form. An Additions and
179letiorts Report that notes added
Information as well as revisions to the
standard form text is available from
the author and should be reviewed. A
vertical line in the left margin of this
document Indioate5 where the author
has added necessary information
and where the author has added to or
deleted from the original AIA text,
This document has important legal
consequences. Consultation with art
attorney is encouraged with respect
to its completion or modification.
Init. AIA Document A201 T" - 2007. Copyright $ 1911. 191$. 191 a. 1925, 1937, 1951, 1958. 1981. 1963, 1966, 1970, 1978, 1967. 199P and 2007 by The American
Institute of Architects. All rights reserved, WARNING: This AIA9° Document Is protected by U.S. Copyright Law and International Treaties. Unauthorized 1
reproduction or distribution of this AIAd° Document, or any portion of it, may scull in severe civil and criminal ponaltlos, and will be prosecuted to the
! maximum extant possible under the law. This document was produced by AIA saflware tit 1$;04;44 On UUIW2014 under Order No,2901087948_1 which expires
on 0912012014, and is not for resale.
User Notes: (1213612647)
INDEX
(Topics and numbers in hold are section headings.)
Acceptance of Nonconforming Work
9.6.6, 9.9.3, 12.3
Acceptance of Work
9.6,6, 9.8,2, 9.9.3, 9.10.1.9.10.3, 12.3
Access to Work
3,16, 6.2.1, 12.1
Accident Prevention
10
Acts and Omissions
3.2, 3.3.2, 3.12.8, 3.18, 4.2.3, 8.3.1, 9.5.1, 10,2.5,
10.2.8, 13.4.2, 13.7, 14.1, 15.2
Addenda
1.1.1, 3.11
Additional Costs, Maims for
3.7.4, 3.7.5, 6.1.1, 7.17.5, 10.3, 15.1.4
Additional Inspections and Testing
9.4.2, 9.8.3, 12.2.1, 13.5
Additional Insured
11.1.4
Additional 'rime, Claims for
3.2.4, 3.7-4, 3,T5, 3.10.2, 8.3.2, 15.1.5
Administration of the Contract
3.1.3, 4.2, 9.4, 9.5
Advertisement or Invitation to Bid
Aesthetic Effect
4 2.13
Allowances
3.8, 7.3.9
All-risk Insurance
11.3.1, 11.3.1.1
Applications for Payment
4 2.5, 7.3.9, 9.2, 9.3. 9.4, 9.5.1, 9.6.3, 9.7, 9.10, 11.1.3
Approvals
2.1.1, 2.2.2, 2.4, 3.1.3, 3.10.2, 3.118, 3.12.9, 3.12,10,
4.2.7, 9.3.2, 13.5.1
Arbitration
8.3.1,11.3.10,13.1,15,3.2,15.4
ARCHITECT
4
Architect, Definition of
4.1.1
Architect, Extent of Authority
2.4,3.12.7,4.I,4.2,5.2,6.3,7.1.2,7.3.7,7.4,9.2,
9.3.1,9.4,9.5,9.6.3,9.8,9.10.1,9.10.3, 12.1, 12.2.1,
13.5.1, 13.5.2, 14.2.2, 14.2.4, 15 , 1. 3, 15.2.1
Architect, Limitations of Authority and Responsibility
2,1,1,3.12.4,3.12.8,3.12.10,4.1.2,4.2.1,4.2.2,4.2.3,
4.2.6, 4.2.7, 4.2.10, 4.112, 4.2.13, 5.2.1, 7A. 9,4.2,
9,5.3, 9,6.4, 15.13, 15.2
Architect's Additional Services and Expenses
2.4, 11.3.1.1, 12.2.1, 13.5.2, I15,3, 14.2.4
Architect's Administration of the Contract
3.1.3, 4.2, 3.7,4, 15,2, 9.4.1, 9.5
Architect's Approvals
2.4, 3.1.3, 3.5, 3.10.2, 4.2.7
Architect's Authority to Reject Work
3.5, 4.2.6, 12.1.2, 12.2.1
Architect's Copyright
1.1.7, 1.5
Architect's Decisions
3.7.4, 4.2.6, 4.2.7, 4.2. 11, 4. 2. 12, 4.2.13, 4.2. 14, 6.3,
7.3.7, 7.3.9, 8,1.3, 8.3.1, 9.2, 9.4.1, 9.5, 9.8,4, 9.9.1,
13.5.2, 15.2, 15.3
Architect's Inspections
3.7.4, 4.2.2, 4.2.9, 9,4.2, 9.8.3, 9.9.2, 9.10.1, 13.5
Architect's instructions
3.2.4, 3.3.1, 4.2.6, 4.2.7, 13.5.2
Architect's Interpretations
4.2,1 1, 4,2.12
Architect's Project Representative
4.2.10
Architect's Relationship with Contractor
1.1.2, 1.5, 3.1.3, 3.2.2, 3.2.3, 3.2.4, 3.3.1, 3.4.2, 3.5.
3.7A,3.7.5,3.9.2,3.9.3,3.10,3.11,3.12,3,16,118,
4.1.2, 4.1.3, 4.2, 5.2, 6.2.2, 7, 8.3.1, 9.2, 9.3, 9.4, 9.5,
9.7, 9.8, 9.9, 10.2.6, 10.3, 11.3.7, 12, 13.4.2, 13.5, 15.2
Architect's Relationship with Subcontractors
1.1.2, 4.2,3, 4.2.4, 4.2.6, 9.6.3, 9.6.4, 11.3.7
Architect's Representations
9.4.2, 9.5.1, 9.10.1
Architect's Site Visits
3.7.4, 4.2.2, 4.2.9, 9.4.2, 9.5.1, 9.9.2, 9.10.1, 13.5
Asbestos
10.3.1
Attorneys' Fees
3,18,1, 9.10,2, 10,3.3
Award of Separate Contracts
6.1.1, 6.1.2
Award of Subcontracts and Other Contracts for
Portions of the Work
5.2
Basic Dellnitions
1.1
Bidding Requirements
1,1,1,5.2,1, 11.4.1
Binding Dispute Resolution
9.7, 11.3.9, 11.3.10, 13.1, 15.2.5, 15.2.6.1, 15.3.1,
15.3.2, 15.4.1
Boiler and Machinery Insurance
l 1.3.2
Bonds, Lien
7.3.7.4, 9.10.2, 9.10.3
Bonds, Performance, and Payment
7.3.7.4, 9.6.7, 9.10.3. 1 1.1% 11.4
Building Permit
3.7,1
AIA Document A20111 - 2M. Copyright Z 1911, 1915. 1916. 1925. 1937. 1951. 1958, 196t, 1963. 1996, 1970, 1976. 1987. 1997 and 2007 by The Amarlcan
kilt tnatitute of Architects. All rights reserved. WARNING- This AIAe Document Is protected by U-S. Copyright Law and International Treaties. Unauthorized
reproduction or distribution of this AIA° nocument, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the
maxlmum extent possible under tha law. This document was produced by AIA software at 15 04:44 on 06110i2014 under Order No.2901087948,_1 which expires
on 0912012014,and is not for resale.
Utter Notes: (12i W 2647)
Capitalization
1.3
Certificate of Substantial Completion
9.8.3, 9.8.4, 9.8.5
Certificates for Payment
4.2.1, 4.2.5, 4.2.9, 9.3.3, 9.4, 9.5, 9.6.1, 9.6.6, 9.7,
9,10, I, 9,10.3, 14.1.1.3, 14.2,4, 15.1.3
Certificates of Inspection, Testing or Approval
13.5.4
Certificates of Insurance
9.10.2, 1 1.1.3
Change Orders
I.1.1,2,4,3.4.2,3.7.4,3.8.2.3,111,3.12.8,4.2.8,
5.2.3,7.1.2,7.1.3,7.2,7.3.2,7.3.6, 7.3.9,7.3.10,8.3.1.
9.3. I.1, 9.10.3, 10.3,2, 11.3.1.2, 11.3.4, 11.3.9, 12.1.2,
15.1.3
Change Orders, Definition of
7.2.1
CHANGES IN THE WORK
2.2.1, 3.11, 4.2.8, 7, 7.2.1, 7.3.1, 7.4, 8.3.1, 9.3. 1. 1,
1 1.3.9
Claims, Definition of
15.1.1
CLAIMS AND DISPUTES
3.2.4, 6.1.1, 6.3 , 7.3.9, 9.3.3, 9.10.4, 10.3.3, 15, 15.4
Claims and'rimely Assertion of Claims
15.4,1
Claims for Additional Cost
3,2.4, 3.7.4, 6.1.1, 7.3.9, 10.3.2, 15.1.4
Claims for Additional Time
3.2.4,3.7.4,6.1.1,8.3.2. 10.3.2,15.1.5
Concealed or Unknown Conditions, Claims for
3.7.4
Claims for Damages
3.2.4, 3.18, 6.1.1, 8.3.3, 9.5.1, 9.6.7, 10.3.3, 11.1.1,
1 I.3.5 , 1 1.3.7 , l 4.1.3 , 14.2.4, 15.1.6
Claims Subject to Arbitration
15.3.1, 15.4.1
Cleaning Up
3,15, 6.3
Commencement of the Work, Conditions Relating to
2.2.1, 3.2.2, 3.4.1, 3.7.1,3.10,1, 3,12.6, 5,2.1, 5.2.3,
6.2.2, 8.1.2, 8.2.2, 8.3.1, 1 I . 1, 11.3.1, 11.3.6, 1 1.4.1,
15.1.4
Commencement of the Work, Definition of
8.1.2
Communications )Facilitating Contract
Administration
3.9.1, 4.2.4
Completion, Conditions Relating to
3,4,1, 3.1 I, 115. 4.2.2, 4.2.9, 8.2, 9.4.2, 9.8, 9.9.1,
9, t 0, 12.2, l 3.7, 14.1.2
COMPLETION, PAYMENTS AND
9
Completion, Substantial
4.2.9, 8.1.1, 9.1.3, 8.23, 9,4.2, 9,8, 9.9, I, 9.10.3, 12.2,
13.7
Compliance with Laws
1.6, 3.2.3, 3.6, 3.7, 3,12.10, 3.13, 4.1.1, 9.6.4, 10.2.2,
11. 1, 11.3, 13.1, 13.4, 13.5.1, 13.5.2, 13.6, 14. 1. 1,
14.2.1.3, 15.2.8, 15,4.2, 15.4.3
Concealed or Unknown Conditions
3,7.4, 4.2.8, 8.3.1, 10.3
Conditions ofthe Contract
1.1.1, 6.1.1, 6,1.4
Consent, Written
3.4.2, 3.7.4, 3.12.8, 3.14.2, 4.1.2, 9.3.2, 9.8.5, 9.9.1,
9,10.2, %10.3, 11,3.1, 13,2, 13.4.2, 15,4,42
Consolidation or Joinder
1 +.4.4
CONSTRUCTION BY OWNER OR BY
SEPARATE CONTRACTORS
1.1.4, 6
Construction Change Directive, Definition of
7.3.1
Construction Change Directives
1.1.1, 3.4.2, 3.12.8, 4.2,8, 7,1,1, 7,1,2, 7.1.3, 7.3,
9.3.1.1
Construction Schedules, Contractor's
3.10,3.12.1,3,122,6.1.3, 15,1.5.2
Contingent Assignment of Subcontracts
5.4, 14.2.2.2
Continuing Contract Performance
15.1.3
Contract, Definition of
1,1.2
CONTRACT, TERMINATION OR
SUSPENSION OF THE
5.4,1,1, 11,3.9, 14
Contract Administration
3.1.3, 4, 9.4, 9.5
Contract Award and Execution, Conditions Relating
to
3.7.1, 3.10, 52, 6, I, 11.1.3, 1 1,3,6, 11 A4 1
Contract Documents, Copies Furnished and Use of
1.5.2, 2.2.5, 5.3
Contract Documents, Definition of
1.1.1
Contract Sum
3.7.4, 3.8, 5.2.3, 7.2, 7.3, 7.4, 9.1, 9A.2, 9.5.1.4, 9.6.7,
9.7, 10.3.2, 11.11, 14.2.4, 143.2, 15.1.4, 15.2.5
Contract Sum, Definition of
9.1
Contract Time
3.7.4, 3.7.5, 3.10.2, 5.2.3, T2.13, 7.3.1, 7.3.5, 7.4,
8.1,1, 8.2.1. 8.3.1, 9.5.1, 9.7, 10.3.2, 12.1.1, 14.3.2.
15.1.5.1, 15.2.5
Contract Time, Definition of
8.1.1
CONTRACTOR
3
Contractor, Definition of
11, 6.1.2
Init. AIA Document A201Tm — 2007. Copyright (D1911, 1915, 1918, 1825, 1937, i951, 1958, 1981, 1963. 1986, 1970, 1978, 1907. 1997 and 2007 by The American
Ins111ute of Architects. All rights reserved. WARNING: This AIA' Document is protected by U.S. Copyright Law and International Treatlos. Unauthorized
reproduction or distribution of this AIA' Document, or any portion of it, may result In severe civil and criminal penalties, and will be prosecuted to the
j maximum extent possible under the law. This document was produced by AIA software at 15,04,44 on 0611012014 under Order No.2901087948_1 which expires
on 0912012014, and is not forfe6ale.
User Notes: (1213612647)
Contractor's Construction Schedules
3.10,3.12.1, 3.12.2,6.1.3, 15.1.5.2
Contractor's Employees
3.3.2, 3.4.3, 3Z1, 3.9, 3.18.2. 4.2.3, 4.2.6, 10.2, 10.3,
11,1,1, 11.3.7, 14,1, 14,11.1
Contractor's Liability Insurance
11.1
Contractor's Relationship with Separate Contractors
and Owner's Forces
3.12.5, 3.14.2, 4,2.4, 6, 1 1.3.7, 12.1.2, 12.2A
Contractor's Relationship with Subcontractors
1.2.2, 3.3.2, 3.18.1, 3.18.2, 5, 9.6.2, 9.6,7, 9.10.2,
11,3,1.2. I1.3,7, 11.3,8
Contractor's Relationship with the Architect
1.1.2, 1.5, 3.1.3, 3.2.2, 3.23, 3,2.4, 3.3.1, 3.4.2, 3.5,
3.7.4, 3.10, 3.1 1, 3.12, 3.16, 3,18, 4.1.3, 4.2, 5.2, 6.2.2,
7, 8.11, 9.2, 9.3, 9.4, 9.5, 9.7, 9.8, 9.9, 10.2.6, 10.3,
11.3.7, 12, 13.5, 15.1.2, 15.2.1
Contractor's Representations
3.2.1, 3,12, 3.5, 3.12.6, 6.2.2, 8.2.1, 9.3.3, 9.8.2
Contractor's Responsibility for Those Performing the
Work
3.12, 3, I8, 5.3, 6.1.3. 6.2, 9.5.1, 10.2.8
Contractor's Review of Contract Documents
3,2
Contractor's Right to Stop the Work
9.7
Contractor's Right to Terminate the Contract
14.1, 15.1.6
Contractor's Submittals
3.10, 3.11, 3.12.4, 4.2,7, 521, 5.2.3, 9.2, 9.3, 9.8.2,
9.8.3, 9,9.1, 9,10.2, 9.10.3, 11.1.3, 1 1.4.2
Contractor's Superintendent
3.9, 10.2.6
Contractor's Supervision and Construction
Procedures
1.12, 3.3. 3.4, 3,12.10, 4.2.2, 4.2.7, 6.1.3, 6.2.4, 7.1.3,
7.3.5, 7.3.7, 8.2, 10, 12, 14, 15.1.3
Contractual Liability Insurance
11.2
Coordination and Correlation
1.2,3.2.1,3.3.1,3.10,3.12.6,6.1.3,6.2.1
Copies Furnished of Drawings and Specifications
1.5, 2.2.5, 3,11
Copyrights
1.5, 3.17
Correction of Work
2.3, 2.4, 3.7.3, 9.4.2, 9,8.2, 9,8.3, 9.9.1, 12.1.2, 12.2
Correlation and intent of the Contract Documents
1,2
Cost, Definition of
7.3.7
Costs
2.4, 3.2.4, 3.7.3, 3.8.2, 3,15.2, 5.4.2, 6.1.1, 6.2.3,
7.3.3.3, 7.3.7, 7.3.8, 7.3.9, 9.10.2, 10.3.2, 10.3.6, l 1.3,
12.1.2, 12.2.1, 12.2.4, 13.5, 14
Cutting And Patching
3.14, 6.2.5
Damage to Construction of Owner or Separate
Contractors
3.14.2, 624, 10.2.1.2, 10.2.5, 10.4, 11.1.1, 1 1.3,
12.2.4
Damage to the Work
3.14.2, 9.9.1, 10.2.1.2, 10.2.5, 10.4, 11.3.1, 12.2.4
Damages, Claims for
3.2.4, 3.18, 6.1.1, 8.3.3, 9.5.1, 9.6.7, 10.3.3, 1 1.1.1,
11.3.5, 11.3.7, 14.1.3, 14.2.4, 15.1.6
Damages for Delay
6.1.1, 8.3.3, 9.5.1.6, 9.7, 10.3. 2
Date of Commencement of the Work, Definition of
8.1.2
Date of Substantial Completion, Definition of
8.1.3
Day, Definition of
8.1.4
Decisions of the Architect
3.7.4, 4.2.6, 4,23, 4,2.1 1, 4.2,12, 4.2,13, 15.2, 6.3,
7.3 3, 7.3.9, 8.1.3, 8.3.1, 9.2, 9.4, 9.5.1, 9.8.4, 9.9. 1,
13.5.2, 14.2.2, 14.2.4, 15.1, 15.2
Decisions to Withhold Certification
9.4.1, 9.5, 9.7, 14.1.1.3
Defective or Nonconforming Work, Acceptance,
Rejection and Correction or
2.3, 2.4, 3.5, 4.2.6, 6.15, 9.5.1, 9.5.2, 9.6.6, 9.8.2,
9.9.3, 9.10.4, 12.2.1
Definitions
1.1, 2.1.1,3.1.1,3.5,3.12.1,3.12.2,3.12.3,4.1.1,
15.1.1,5.1,6.1.2,7.2.1,7.3.1,8.1,9.1,9.8.1
Delays and Extensions of Time
3.2, 3.7.4, 5.2.3, 7.2.1, 7.3.1, 7.4, 8.3, 9.5.1, 9.7,
10.3.2, 10.4, 14.3.2, 15.1.5, 15.2.5
Disputes
6.3, 7.3.9, 15.1, 15.2
Documents and Samples at the Site
3.11
Drawings, Definition of
1.1.5
[drawings and Specifications, Use and Ownership of
3.11
Effective Date of insurance
8.2.2, 1 1.1.2
Emergencies
10A. 14.1 A Z 15,1 A
Employees, Contractor's
3.3.2, 3.4.3, 3,8,1, 3.9, 3,13.2, 4.23, 4,2,6, 10,2,
10.3.3,Ii.l.l,11.3.7,14.1,14.2.1.I
Equipment, Labor, Materials or
1.1.3, 1.1.6,3.4,3.5,3.8.2,3.8.3,112,3.13,3.15.1,
4.2.6, 4.2.7, 52, I , 6,2,1, 7.3.7, 9.3.2, 93.3, %5,1.3,
9.10.2, 10.2.1, 10.2.4, 14.2.1.1, 14.2.1.2
AIA Document A201" — 2007. Copyright Q 1911. 1915, 1918, 1925, 1937. 1951, 1959, 1961. 19153, 1969. 1970, 1976, 1987. 1997 and 2007 by The American
Init. Institute of Architects. All rights reserved. WARNING: This AIAI document Is protected by U.S. copyright Law and International Treaties. Unauthorized
reproduction or distribution of this AIA+ Document, or any portion of it, may result In severe civil and criminal penalties, and will he prosecuted to the
f maximum extent pasaibla under the law. This document was produced by AIA software at 15:04;44 an 06110120i4 under Order No.2901087948_1 which expires
on 0912012014. and is not for resale.
!Jeer Notes; (1213612647)
Execution and Progress of the Work
1.1.3, 1.2.1, 1.2.2, 2.2.3, 2.2.5, 3.1, 3.3.1, 3.4.1, 3.5,
3.7.1, 3.10.1, 3.12, 3.14, 4.2, 6.2.2, 7.1.3, 7.3.5, 8,2,
9,5,1,9.9.1, 10.2, 10.3, 12.2, 14.2, 14.3.1, 15.1.3
Extensions of Time
3.2.4, 3.7.4, 5.2.3, 7.2.1, 7.3, 7.4, 9.5.1, 9.7, 10,3.2,
10.4, 14.3, 15,1,5, 15.2,5
Failure of Payment
9.5.1.3, 9.7, 9.10.2, 13.6, 14.1.1.3, 14.2.1.2
Faulty Work
(See Defective or Nonconforming Work)
Final Completion and Final Payment
4.2,1, 4.2.9, 9.8.2, 9.10, 11.1.2, 11.1.3, 11.3.1, 11.3.5,
12.3, 14.2.4, 14.4.3
Financial Arrangements, Owner's
2,2,1, 13.12, 14.LL4
Fire and Extended Coverage Insurance
11.3.1.1
GENERAL PROVISIONS
I
Governing Law
13.1
Guarantees (See Warranty)
Hazardous Materials
10.2.4, 10.3
Identification of Subcontractors and Suppliers
5.2,1
Indemnification
3,17, 3.18, 9.10.2, 10.3.3, 10.3.5. 10.3.6, 11.3.1.2,
11.3.7
Inrormation and Services Required of the Owner
2.1.2, 2.2, 3.2.2, 3.12.4, 3.12.10, 6.1.3, 6.1.4, 6.2.5,
9.6.1, 9.6.4, 9.9.2, 9.10.3, 10.33, 1 1.2, 11A, 13.5.1,
115.2, 14.1.1.4, 14.1.4, 15.1.3
Initial Decision
15.2
Initial Decision Maker, Definition of
1.1.8
Initial Decision Maker, Decisions
l 4.2.2, 14.2.4, 15.2.1, 15.2.2, 15.2.3, 15.2.4, 15.2.5
Initial Decision Maker, Extent of Authority
14.2.2, 14,2.4, 15.13, 15.2.1, 15.2,2, 15,2.3, 15,2,4,
15.2.5
Injury or Damage to Person or Property
10.2.8, 10.4
Inspections
3.1.3, 3.3.3, 3.7.1, 4.2.2, 4.2.6, 4.2.9, 9.4.2, 9.83,
9.9.2, 9,10.1, 12.2.1, 13.5
Instructions to Bidders
Instructions to the Contractor
3.2.4, 3.3.1, 3.8.1, 5.2.1, 7, 8.2.2, 12, 13.5.2
Instruments of Service, Definition of
1.1.7
Insurance
6.1.1,7.3.7,9.3.2,9.8.4,9.9.1,9.10.2,11
Insurance, Boiler and Machinery
11.3.2
Insurance, Contractor's Liability
11,1
insurance, Effective Date of
8.2„2, 11,1.2
Insurance, Loss of Use
11.3.3
Insurance, Owner's Liability
11.2
Insurance, Property
10.2.5, 11.3
Insurance, Stored Materials
9,3,2
INSURANCE AND BONDS
II
Insurance Companies, Consent to Partial Occupancy
9.9.1
Intent of the Contract Documents
1.2.1, 4.2.7, 4.2,12, 4.2,13, 7A
Interest
13.6
Interpretation
1.2.3. 1.4, 4.1.1, 5.1, 6.1.2. 15.1.1
Interpretations, Written
4.2.11,4.2.12, 15.1.4
Judgment on Final Award
15.4.2
Labor and Materials, Equipment
1.1.3, 1.1.6, 3.4, 3.5, 3.8.2, 3.8.3, 3.12, 3.13, 3. I5.1,
4.2.6, 4.2.7, 5.2.1, 6.2.1, 7.3.7, 9.3.2, 9.3.3,
9.10.2, 10.2,1, 10.2.4, 14.2.1.1, 14.2. 12
Labor Disputes
8.3.1
Laws and Regulations
1.5. 3.23, 3.6, 3.7. 3.12.10, 3.13, 4.1.1. 9.6.4, 9.9.1,
10.2.2, ILIA, 11.3.13.I,13.4,13.5.1,13.5.2,13.6,
14, 15.2.8, 15A
Liens
2.1.2, 9.3.3, 9.10.2, 9.10.4, 15.2.8
Limitations, Statutes of
12.2.5, 13.7, 15.4.1.1
Limitations of Liability
23, 3.2.2, 3,5, 3,12,10, 3,17, 3.18.1. 426, 4.2,7,
4.2.12, 6.2.2, 9.4.2, 9.6.4, 9.6.7, 10.2.5, 10.3.3, 11.1.2,
1 1.2, 11.3.7, 12.2.5, 13.4.2
Limitations of Time
2.1.2, 2.2, 2.4, 3.2.2, 3.10, 3.11, 3.12.5, 3.15.1, 4.2.7,
5.2,5.3,5.4,1,6.2.4,7.3,7.4, 8.2,9.2,9.3.1,9.3.3,
9.4.1, 9.5, 9.6, 9.7, 9.8, 9.9, 9.10, 11. L3, 11.3.1.5,
1 1.3.6, 11.3.10, 12.2, 13.5, 13.7, 14, 15
Loss of Use Insurance
11.3.3
Material Suppliers
1.5, 3.12.1, 4.2.4, 4.2.6, 5.2.1, 9.3, 9.4.2, 9.6, 9.10.5
Materials, Hazardous
10.2.4, 10.3
Init. AIA Document A2¢i I" — 2Op7. Copyright � 1911. 1915, 1918, 1925, 107, 101, 19$9, 1981, 1953, 1960, 1970, 1976, 191;7, 1997 and 2007 6y The American
institute of Archltecl& All rights reserved, WARNING; This AIA1 Document is protected by U.S. Copyright Law and International Treaties, Unauthorized
reproduction or distribution of this AIA11 Documont, or any portion of It, may result In severe civil and crintlnal panalties, and will ha prosecuted to the
maximurn extent possible under the law. This document was produced by AIA software at 15:04A4 on OW1012014 under Order No.2901087948w1 which expires
on 0912012014, and is not for resale,
User Notes: 112138126471
Materials, Labor, Equipment and
1. L3, 1.1.6, 1.5.1, 3.4.1, 3.5, 33.2, 3.8.3, 3,12, 3.13,
3.15.1, 4.2,6, 4,2,7, 5.2.1, 6.2.t, 7.3.7, 9.3.2, 9.3.3,
9.5.1.3, 9.10.2, 10.2.1.2, 10.2.4, 14.2.1.1, 14, 2, I , 2
Means, Methods, Techniques, Sequences and
Procedures of Construction
33.1, 3,12,10, 4.2.2, 4.2.7, 9.4.2
Mechanic's Lien
2.1.2, 15.2.8
Mediation
8.3.1,10.3.5,14.3.6,15.2.1,13.2.5,15,2.6,15.3,
15.4,1
Minor Changes in the Work
1.1.1, 3.12.9, 4.2.8, 7.1, 7.4
MISCIELLANEOUS PROVISIONS
13
Modifications, Definition of
1.1.1
Modifications to the Contract
1.L1, I.L2,3.11,4.1.2,4.2.1,5.2.3,7,8.3.1,9.7,
10.3.2, 113.1
Mutual Responsibility
6.2
Nonconforming Work, Acceptance of
9.6.6, 9.9.3, 12.3
Nonconforming Work, Rejection and Correction of
2.3, 2.4, 3.5, 4.2.6, 6.2.4, 9.5.1, 9.8.2, 9.9.3, 9.10.4,
12.2.1
Notice
2.2.1,2.3, 2.4,3.2.4,3.3.1,3.7.2.3.12.9,5.2.1,9.7,
9.10,10.2.2,11.1.3,12.2.2.1,13.3,13.5.1,13.5.2,
14.1, 14.2, 15.2.8, 15.4.1
Notice, Written
2.3, 2.4, 3.3.1, 3.9.2, 3.12.9, 3.12.10, 5.2.1, 9.7, 9. 10,
10.2.2, 10.3, 1 1. l .3, 1 1.3.6, 12.2.2.1, 13.3, 14, 15.2.8,
15.4.1
Notice of Claims
3.7A, 10.2.8, 15.I.2, 15.4
Notice of Testing and Inspections
13.5.1, 13.5.2
Observations, Contractor's
3,2, 3.7.4
Occupancy
2.2.2, 9.6.6, 9.8, 11.3.1.5
Orders, Written
1.1.1, 2.3, 3.9.2, 7, 8.2.2, 1 1.3.9, l 2.1, 12.2.11, 13.5.2,
14.3.1
OWNER
2
Owner, Definition of
2.1.1
Owner, Information and Services Required of the
2,1.2, 2.2, 3.2.2, 3. l 2.10, 6.1.3, 6.1.4, 6.2.5, 9.3.2,
9.6.1.9.6.4, 9.9.2, 9.10.3, 10.3.3, 1 1.2, 1 1.3, 13.5.1,
13.5.2, 14.1.1.4,14.1.4, 15.1.3
Owner's Authority
1.5,2.1.1,2.3,2.4,3.4.2,3.8.1,3.12.10,3.14.2,4.1.2,
4. 1.3, 4.2.4, 4.2.9, 5.2.1, 5.2.4, 5.4.1, 6A, 6.3, 7.2.1,
7.3.1. 8.2.2, 8.3.1, 9.3.1, 9.3.2, 9.5.1, 9.6.4, 9.9,1,
9.10.2, 10.3.2. 11.1.3, 11.3.3. 11.3.10, 12.2.2, 12.3,
13.2.2, 14.3, 14.4, 15.2.7
Owner's Financial Capability
2.2.1, 13.2.2, 14.1.1.4
Owner's Liability Insurance
11.2
Owner's Relationship with Subcontractors
1.1.2, 5.2, 5.3, 5.4, 9.6.4, 9.10.2, 14,2.2
Owner's Right to Carry Out the Work
2.4, 14.2.2
Owner's Right to Clean Up
6.3
Owner's Right to Perform Construction and to
Award Separate Contracts
6.1
Owner's Right to Stop the Work
2.3
Owner's Right to Suspend the Work
14.3
Owner's Right to Terminate the Contract
14.2
Ownership and Use of Drawings, Specifications
and Other Instruments of Service
1.1.1, 1.1,6, 1,1.7,1.5,2.2.5,3.2.2,3.11,3.17,4.2.12,
5.3
Partial Occupancy or Use
9,6.6, 9.9, 1 1.3.1 �5
Patching, Cutting and
3.14, 6.2.5
Patents
3.17
Payment, Applications for
4.2.5, 7.3.9, 9.2, 9.3, 9.4, 9.5, 9.6.3, 9.7, 9.8.5, 9. 10. 1,
14.2.3. 14.2.4, 14.4.3
Payment, Certificates for
4.2.5, 4.2,9, 93.3, 9.4, 9.5, 9,6. I, 9.6.6, 9.7, 9,10.1,
9.10.3, 13.7, 14.1.1.3, 14.2.4
Payment, Failure of
9,5.1.3, 9.7, 9.10.2, 13.6, 14.1.1.3, 14.2. L2
Payment, Final
4.2.1, 4.2.9, 9.8.2, 9,10, 1 1.1.2, 11.1.3, 1 I,4.1, 12.3,
13.7, 14.2.4, 14.4.3
Payment Bond, Performance Bond and
7.3.7A, 9.6,7, 9.10.3. 11.4
Payments, Progress
9.3, 9.6, 9.8.5, 9.103, 13.6, 14,2.3, 15.13
PAYMENTS AND COMPLETION
9
Payments to Subcontractors
5.4.2, 9.5.1.3, 9.6.2, 9.6.3, 9.6.4, 9.6.7, 14.2.1.2
PCB
10.3.1
Ini#. AlA Dpt=um$nt A2p1 T" — 2p47' Copyright 0 1911, 1915. 1918, 1925, 1937. 1951. 1958, 1961. 1963, 1966. 1970. 1976, 1987, 1997 and 2007 by The American
Institute of Archit9ols. All rights reserved. WARNING: This AIA11 Document Is protected by U.S. Copyright Law and International TruatiuS. Unauthorized
reproduction or dlstribution of this AIA11 Document, orany portion of it, may result in Severe civil and criminai penalties, and will be prosecuted to the
r maximum extent possible under the law. This document was produced by AIA software at 15:04:44 on 0811012014 under Order No.2901067948_1 which expires
on 0912012014, and is not for resale.
User Notes: (1213612647)
Performance Bond and Payment Bond
7.3.7.4, 9.6.7, 9.10.3, 11.4
Permits, Fees, Notices and Compliance with Laws
2.2.2, 3.7, 3.13, 7.3.7.4, 10.2.2
PERSONS AND PROPERTY, PROTECTION OF
t0
Polychlorinated Biphenyl
10.3.1
Product Data, Definition of
3.12.2
Product Data and Samples, Shop Drawings
3.1 I, 3,12,4.2.7
Progress and Completion
4.2.2, 8.2, 9.8, 9.9.1, 14.1.4, 15.1.3
Progress Payments
9.3, 9.6, 9.8.5, 9.10.3, 13.6, 14.2.3, 15.1.3
Project, Definition of
1.1.4
Project Representatives
4.2.10
Property Insurance
IO.2.5, 11.3
PROTECTION OF PERSONS AND PROPERTY
10
Regulations and Laws
1.5, 3.2.3, 3.6, 3.7, 3.12,10, 3.13, 4,1.1, 9.6.4, 9.9.1,
10.2.2, 11.1, 11.4, 13.1, 13.4, 13.5.1, 13.5.2, 13.6, 14,
15.2.8, 15.4
Rejection of Work
3,5, 4.2,6, 12.2,1
Releases and Waivers of Liens
9.10.2
Representations
3.2.1. 3.5,3.12.6, 6.2.2, 9.2.1,9.3.3, 9.4.2, 9.5.1, 9.8.2,
9.10.1
Rcprescntatives
2.1.1,3.1.1,3.9,4.1.1,4.2.1,4,2.2,4.2.10,5.1.1,5.1.2,
13.2.1
Responsibility for Those Performing the Work
3.3.2,3.18,4.2.3,5.3,6.1.3,6.2,6.3,9.5.1, 10
Retain age
9.3.1, 9.6.2, 9.8.5, 9.9.1, 9.10.2, 9.10.3
Review or Contract Documents and Field
Conditions by Contractor
3.2, 3,12.7, 6.1.3
Review of Contractor's Submittals by Owner and
Architect
3.10.1, 3.10.2, 3. 11, 3.12, 4.2, 5.2, 6.1.3, 9.2, 9.8.2
Review of Shop Drawings, Product Data and Samples
by Contractor
3.12
Rights and Remedies
1.1.2, 2.3, 2.4, 3.5, 3.7.4, 3.15.2, 4.2.6, 5.3, 5.4, 6.1,
6.3, 7.3.1, 8.3, 9.5.1, 9.7, 10.2.5, 10.3, 12.2.2, 12.2.4,
13.4, 14, 15A
Royalties, Patents and Copyrights
3.17
Rules and Notices for Arbitration
15,4,1
Safety of Persons and Property
10.2, 10.4
Safety Precautions and Programs
3.3.1, 4.2.2, 4.2.7, 5.3, 10.1, 10.2, 10.4
Samples, Definition of
3.12.3
Samples, Shop Drawings, Product Data and
3.11, 3.12, 4.2.7
Samples at the Site, Documents and
3.11
Schedule of Values
9.2, 9.3.1
Schedules, Construction
3.10, 3.12.1, 3.12.2, 6.1.3, 15.1.5.2
Separate Contracts and Contractors
1.1.4, 3.12.5, 3.14.2, 4.2.4, 4.2.7, 6, 8.3.1, 12.1.2
Shop Drawings, Definition of
3.12.1
Shop Drawings, Product Data and Samples
3.1 1, 3.12, 4.2,7
Site, Use of
6.2.1
Site Inspections
3.2.2, 3.3.3, 3,7,1, 3,7.4, 4.2, 9.4.2, 9,10.1, 13.5
Site Visits, Architect's
3.7.4, 4.2.2, 4.2.9, 9.4.2, 9.5.1, 9.9.2, 9.10.1, 13.5
Special Inspections and Testing
4.2.6, 12.2. l , 115
Specifications, Definition of
1.1.6
Specifications
1.1.1, 1.1.6, 1.2.2, L5, 3.1 1, 3.12.10, 3.17, 4.2.14
Statute of Limitations
13.7, 15.4.1.1
Stopping the Work
2.3, 9,7, 10.3, 14.1
Stored Materials
6.2.1, 9.3.2, 10.2.1.2, 10.2.4
Subcontractor, definition of
5.1.1
SUBCONTRACTORS
5
Subcontractors, Work by
1,2,2, 3,3.2, 3,12, I, 4,2.3, 5.2.3, 5.3, 3A, 9,3,1,2, 9,6.7
Subcontraetual Relations
5.3, 5.4, 9.3.1.2, 9.6, 9.10, 10.2.1, 14.1, I 4.2.1
Submittals
3.10, 3.11, 3.12, 4.2.7, 5.2.1, 5.2.3, 7.3.7. 9.2, 9.3, 9.8,
9.9.1, 9.10.2, 9.10.3, 11.1.3
Submittal Schedule
3.10.2, 3.12.5, 4.2.7
Subrogation, Waivers of
6,1,1, 11.3.7
AIA Document A201'" — 2007. Copyrlght 01911, 1915, 1918, 1925. 1937, 1951, 1958. 1961, 1963, 1966, 1970, 1976. 1987, 1997 and 2007 by The Amerieen
Init. Institute of Architects. All rights reserved. WARNING: This AIA11 Document Is protected by U.S. Copyright Law and Intemational Treaties. Unauthorized
reproduction or distribution of this AtA'l Document, or any portion of it, may result in sovare civil and criminal penalties, and will be prosecuted to the
1 maximum extent possibio under tho law. This document was produced by AIA software al 15:04:44 on 06/1012014 under Order No.2901087948_1 which expires
on 0912012014, and is not for resole,
User Notes: (1213612647)
Substantial Completion
4,19, 8.1.1, 8.1.3, 8.2.3, 9.4.2, 9.8, 9.9- I, 9.10.3, 12.2,
13.7
Substantial Completion, Definition of
9.8.1
Substitution of Subcontractors
5.2,3, 5,2,4
Substitution of Architect
4.1.3
Substitutions of Materials
3,4.2, 3.5, 7.18
Sub -subcontractor, Definition of
5.1.2
Subsurface Conditions
3.7.4
Successors and Assigns
13.2
Superintendent
3.9, 10,2,6
Supervision and Construction Procedures
1.2.2, 3.3, 3.4, 3.12.10, 4.2.2, 4.2.7, 6.1.3, 6.2.4, 7.1.3,
7,3,7, 8.2, 8,3,1, 9,4.2, 10, 12, 14, 15.1.3
Surety
5.4.1.2, 9.8.5, 9.10.2, 9.10.3, 14.12, 15.17
Surety, Consent of
9.10.2, 9.10.3
Surveys
2.2.3
Suspension by the Owner for Convenience
14.3
Suspension of the Work
5,4,2, 143
Suspension or Termination of the Contract
5.4.1.1, 14
Taxes
3.6, 3.8.2.1, 7.3.7,4
Termination by the Contractor
14.1, 15.1.6
Termination by the Owner for Cause
5.4.1.1, 14,2, 15.1_6
Termination by the Owner for Convenience
14.4
Termination of the Architect
4.1.3
Termination of the Contractor
14.12
TERMINATION OR SUSPENSION OF THE
CONTRACT
14
Tests and Inspections
3.1.3, 3,3.3, 4,2,2, 4.2.6, 4.2.9, 9.4,2, 9.8.3, 9.9.2,
9.10.1, 10.3.2, 11.4.1, 12.2.1, 13.5
TIME
8
Time, Delays and Extensions of
3.2.4, 3.7.4, 5.2.3, 7.2.1, 7.3.1, 7.4, 8.3, 9.5,1, 9,7,
10.3.2, 10.4, 14,12, 15,1.5, 15.2.5
Time Limits
2.1.2, 2.2, 2.4, 3.2.2, 3.10, 3,1 1, 3.12.5, 3.15.1, 4.2,
5.2, 5.3, 5.4, 6.2.4, 7.3, 7.4, 8.2, 9.2, 9.3.1, 9.3.3, 9.4.1,
9.5, 9.6, 9.7, 9.9, 9.9, 9.10, 11.1.3, 12.2, 13.5, 13.7, 14,
15.1.2, 15.4
Time Limits on Claims
3.7.4, 10.18, 13.7, 15.1.2
Title to Work
9.12, 9.3.3
Transmission of Data in Digital Form
1.6
UNCOVERING AND CORRECTION OF WORK
12
Uncovering of Work
12.1
Unforeseen Conditions, Concealed or Unknown
3.7.4, 8.1 1, 10.3
Unit Prices
7.3.3.2, 7.3.4
Use of Documents
1. l .1, 1.5, 2.2.5, 3.12.6, 5.3
Use of Site
3.13, 6.1.1, 6.2.1
Values, Schedule of
9.2, 9.3.1
Waiver of Claims by the Architect
l 3.4.2
Waiver of Claims by the Contractor
9.10.5, 13.4.2, 15.1.6
Waiver of Claims by the Owner
9.9.3, 9.10.3, 9.10.4, 12.2.2.1, 13.4.2, 14.2.4, 15.1.6
Waiver of Consequential Damages
14.2.4, 15.1.6
Waiver of Liens
9.10.2, 9.10.4
Waivers of Subrogation
6.1.1, 11.3.7
Warranty
3.5, 4,2,9, 9.3.3, 9.8.4, 9,9, I, 9,10A 1112, 13,7
Weather Delays
15.1.5.2
Work, Definition of
1.1.3
Written Consent
1.52, 3.4,2, 3.7A, 3.12.8, 3.14.2, 4.1.2, 9.3.2, 9.8.5,
9.9.1, 9.10.2, 9.10.3, 1 1.4. I, 13 2, 13.4.2, I5.4.4.2
Written Interpretations
4.111. 4.2.12
Written Notice
2.3, 2,4, 3.3.1, 3.9, 3,12.9, 3.12.10, 5.2.1, 8.2.2, 9.7,
9.10, 10.2.2, 10.3, 11.1.3, 12.2.2, 12.2.4, 13.3, 14,
15.4.1
Written Orders
1.1.1, 2.3, 3.9, 7, 8.2.2, 12.1, 12.2, 13.5.2, 14.3.1,
15.1.2
Init. AIA Document A201 "" — 2007. Copyright ®1911, 1915. 1918. 1925. 1937, 1951, I M. 1961. 1989. 1966, 1970, 1976, 1987, 1997 and 2007 by The Amerloan
Institute of Architects. All right¢ reserved. WARNING' ThIs AW Dprument Is protected by U-S. Copyright Law and International Treaties. Unauthorized
reproduction or distribution or this Al AID Document, or any portion of it, may result In sov are civil and criminal penalties, and will be prosecuted to the
f maxlrourrl extent pns9lble under the law. This documenl was produced by AIA software at 15:04:44 on 06?1W2014 under Order No.29b1057946_t which expires
an 4912412014, and Is not for resale.
User Notes' (1213612647)
ARTICLE 1 GENERAL PROVISIONS
§ 1.1 BASIC DEFINITIONS
§ 1,1,1 THE CONTRACT DOCUMENTS
The Contract Documents are enumerated in the Agreement between the Owner and Contractor (hereinafter the
Agreement) and consist of the Agreement, Conditions of the Contract (General, Supplementary and other Conditions),
Drawings, Specifications, Addenda issued prior to execution of the Contract, other documents listed in the Agreement
and Modifications issued after execution of the Contract. A Modification is (1) a written amendment to the Contract
signed by both parties, (2) a Change Order, (3) a Construction Change Directive or (4) a written order for a minor
change in the Work issued by the Architect. Unless specifically enumerated in the Agreement, the Contract
Documents do not include the advertisement or invitation to bid, Instructions to Bidders, sample forms, other
information furnished by the Owner in anticipation of receiving bids or proposals, the Contractor's bid or proposal, or
portions of Addenda relating to bidding requirements,
§ 1.1.2 THE CONTRACT
The Contract Documents form the Contract for Construction. The Contract represents the entire and integrated
agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written
or oral. The Contract may be amended or modified only by a Modification. The Contract Documents shall not be
construed to create a contractual relationship of any kind (1) between the Contractor and the Architect or the
Architect's consultants, (2) between the Owner and a Subcontractor or a Sub -subcontractor, (3) between the Owner
and the Architect or the Architect's consultants or (4) between any persons or entities other than the Owner and the
Contractor. The Architect shall, however, be entitled to performance and enforcemcnt of obligations under the
Contract intended to facilitate performance of the Architect's duties.
§ 1.1.3 THE WORK
The term "Work" means the construction and services required by the Contract Documents, whether completed or
partially completed, and includes all other labor, materials, equipment and services provided or to be provided by the
Contractor to fulfill the Contractor's obligations. The Work may constitute the whole or a part of the Project.
§ 1,1ATHE PROJECT
The Project is the total construction of which the Work performed under the Contract Documents may be the whole or
a part and which may include construction by the Owner and by separate contractors.
§ 1.1.5 THE DRAWINGS
The Drawings are the graphic and pictorial portions of the Contract Documents showing the design, location and
dimensions of the Work, generally including plans, elevations, sections, details, schedules and diabgams.
§ 1.1,6THE SPECIFICATIONS
The Specifications are that portion of the Contract Documents consisting of the written requirements for materials,
equipment, systems, standards and workmanship for the Work, and performance of related services.
§ 1.1.7INSTRUMENTS OF SERVICE
Instruments of Service are representations, in any medium of expression now known or later developed, of the tangible
and intangible creative work performed by the Architect and the Architect's consultants under their respective
professional services agreements. Instruments of Service may include, without limitation, studies, surveys, models,
sketches, drawings, specifications, and other similar materials.
§ 1.1.8INITIAL DECISION MAKER
The Initial Decision Maker is the person identified in the Agreement to render initial decisions on Claims in
accordance with Section 15.2 and certify termination of the Agreement under Section 14.2.2.
§ 1.2 CORRELATION AND INTENT OF THE CONTRACT DOCUMENTS
§ 1.2.1 The intent of the Contract Documents is to include all items necessary for the proper execution and completion
of the Work by the Contractor. The Contract Documents are complementary, and what is required by one shall be as
binding as if required by all; performance by the Contractor shall be required only to the extent consistent with the
Contract Documents and reasonably inferable from them as being necessary to produce the indicated results.
Init. AIA Document A201- — 2007. Copyright 01911, 1915, 1918. 1925, M7, 1951, 1958. 1981, 1963, 1966, 1970, 1976, 1967, 1997 and 2007 by The American
Institute of Architects. All rights reserved. WARNING: This AIA" document is protected by U.S. Copyright Law and Intemational Treaties. Unauthorized
reproduction or distribution of this AIA° Document, or any portion of it, may result in savera civil and criminal penalties, and will be prosecuted to the
1 maximum extant possible under the law. This documeni was produced by AIA software ai 15;04:44 on 0&1012014 under Order No. 2901087948_1 which expires
on 0912012014, and is not for resale.
User Notes: (1213512647j
§ 112 Organization of the Specifications into divisions, sections and articles, and arrangement of Drawings shall not
control the Contractor in dividing the Work among Subcontractors or in establishing the extent of Work to be
performed by any trade.
§ 1.2.3 Unless otherwise stated in the Contract Documents, words that have well-known technical or construction
industry meanings are used in the Contract Documents in accordance with such recognized meanings.
§ 1.3 CAPITALIZATION
Terms capitalized in these General Conditions include those that are (1) specifically defined, (2) the titles of numbered
articles or (3) the titles of other documents published by the American Institute of Architects,
§ 1.4INTERPRETATION
In the interest of brevity the Contract Documents frequently omit modifying words such as "ail" and "any" and articles
such as "the" and "an," but the fact that a modifier or an article is absent from one statement and appears in another is
not intended to affect the interpretation of either statement.
§ 1.5 OWNERSHIP AND USE OF DRAWINGS, SPECIFICATIONS AND OTHER INSTRUMENTS OF SERVICE
§ 1.5.1 The Architect and the Architect's consultants shall be deemed the authors and owners of their respective
Instruments of Service, including the Drawings and Specifications, and will retain all common law, statutory and other
reserved rights, including copyrights. The Contractor, Subcontractors, Sub -subcontractors, and material or equipment
suppliers shall not own or claim a copyright in the Instruments of Service. Submittal or distribution to meet official
regulatory requirements or for other purposes in connection with this Project is not to be construed as publication in
derogation of the Architect's or Architect's consultants' reserved rights.
§ 1.5.2 The Contractor, Subcontractors, Sub -subcontractors and material or equipment suppliers are authorized to use
and reproduce the Instruments of Service provided to them solely and exclusively for execution of the Work. All
copies made under this authorization shall bear the copyright notice, if any, shown on the Instruments of Service. The
Contractor, Subcontractors, Sub -subcontractors, and material or equipment suppliers may not use the Instruments of
Service on other projects or for additions to this Project outside the scope of the Work without the specific. written
consent of the Owner, Architect and the Architect's consultants.
§ 1.6 TRANSMISSION OF DATA IN DIGITAL FORM
If the parties intend to transmit Instruments of Service or any other information or documentation in digital form, they
shall endeavor to establish necessary protocols governing such transmissions, unless otherwise already provided in the
Agreement or the Contract Documents.
ARTICLE 2 OWNER
§ 2.1 GENERAL
§ 2.1.1 The Owner is the person or entity identified as such in the Agreement and is referred to throughout the Contract
Documents as if singular in number. The Owner shall designate in writing a representative who shall have express
authority to bind the Owner with respect to all matters requiring the Owner's approval or authorization. Except as
otherwise provided in Section 4.2,1, the Architect does not have such authority. The term "Owner" means the Owner
or the Owner's authorized representative.
§ 2,1.2 The Owner shall furnish to the Contractor within fifteen days after receipt of a written request, information
necessary and relevant for the Contractor to evaluate, give notice of or enforce mechanic's lien rights. Such
information shall include a correct statement of the record legal title to the property on which the Project is located,
usually referred to as the site, and the Owner's interest therein.
§ 2.2INFORMATION AND SERVICES REQUIRED OF THE OWNER
§ 2.2.1 Prior to commencement of the Work, the Contractor may request in writing that the Owner provide reasonable
evidence that the Owner has made financial arrangements to fulfill the Owner's obligations under the Contract.
Thereafter, the Contractor may only request such evidence if (1) the Owner fails to make payments to the Contractor
as the Contract Documents require: (2) a change in the Work materially changes the Contract Sum; or (3) the
Contractor identifies in writing a reasonable concern regarding the Owner's ability to make payment when due. The
Owner shall furnish such evidence as a condition precedent to commencement or continuation of the Work or the
Init. AIA Docurnerd A20111 — 2007. Copyright C 1911, 1915. 1918. 1925. 1937. 1951, 19$8. 1961. 1953, 1966, 1970, 1976, 1907, 1997 and 2007 by The American
Inslitute of Architects. All rights rasorvaO. WARNING: This AIA1 Document is protected by U.S. Copyright Law and International Treaties, Unauthorized ��
repraduction ar distribution of this AIM Document, or any portion of it, may result In severe civil and criminal penalties, and will be prosecuted to the
j maximum extent possible under the law- This document was produced by AIA software at 15:04:44 on 0511=014 under Order No.290i087948_1 which expires
on 0912012014, and is not for resale.
User Notes: (1213812647)
portion of the Work affected by a material change, After the Owner furnishes the evidence, the Owner shall not
materially vary such financial arrangements without prior notice to the Contractor.
§ 2.2.2 Except for permits and fees that are the responsibility of the Contractor under the Contract Documents,
including those required under Section 3.7.1, the Owner shall secure and pay for necessary approvals, easements,
assessments and charges required for construction, use or occupancy of permanent structures or for permanent
changes in existing facilities.
§ 2.2.3 The Owner shall furnish surveys describing physical characteristics, legal limitations and utility locations for
the site of the Project, and a legal description of the site. The Contractor shall be entitled to rely on the accuracy of
information furnished by the Owner but shall exercise proper precautions relating to the safe performance of the
Work.
§ 2.2.4 The Owner shall furnish information or services required ofthe Owner by the Contract Documents with
reasonable promptness. The Owner shall also furnish any other information or services under the Owner's control and
relevant to the Contractor's performance of the Work with reasonable promptness after receiving the Contractor's
written request for such information or services.
§ 2.2.5 Unless otherwise provided in the Contract Documents, the Owner shall furnish to the Contractor one copy of
the Contract Documents for purposes of making reproductions pursuant to Section 1,5.2.
§ 2,3 OWNER'S RIGHT TO STOP THE WORK
If the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as
required by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner
may issue a written order to the Contractor to stop the Work, or any portion thereof, unti I the cause for such order has
been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner
to exercise this right for the benefit of the Contractor or any other person or entity, except to the extent required by
Section 6.1.3.
§ 2.4 OWNER'S RIGHT TO CARRY OUT THE WORD
If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails
within a ten -lay period after receipt of written notice from the Owner to commence and continue correction of such
default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may
have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments
then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner's expenses
and compensation for the Architect's additional services made necessary by such default, neglect or failure. Such
action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If
payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the
difference to the Owner.
ARTICLE 3 CONTRACTOR
§ 3,1 GENERAL
§ 3.1.1 The Contractor is the person or entity identi Fied as such in the Agreement and is referred to throughout the
Contract Documents as if singular in number. The Contractor shall be lawfully licensed, ifrequired in thejurisdiction
where the Project is located. The Contractor shall designate in writing a representative who shall have express
authority ro bind the Contractor with respect to all matters under this Contract. The term "Contractor" means the
Contractor or the Contractor's authorized representative.
§ 3.1.2 The Contractor shall perform the Work in accordance with the Contract Documents,
§ 3.1.3 The Contractor shall not be relieved of obligations to perform the Work in accordance with the Contract
Documents either by activities or duties of the Architect in the Architect's administration of the Contract, or by tests,
inspections or approvals required or performed by persons or entities other than the Contractor.
Init. AIA Document A2011N — ZOOT. Copyright 0 1911, 1915, 1918. 1925. 1937. 1951, 1956. 1961, 1963. 1966. 1970, 1976. 1987. 1997 and 2007 by The AMerloon
In91itule of AfelldeCts. All rights reserved. WARNING: This AIAe Document Is protected by U.S- Copyright Law and International Treaties, Unauthorized 1
reproduction or distribution of this AIA�l 13"urnOnt, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the
i maximum extent possible under the law. This document was produced by MA software a1 15:04:44 on 06110/2014 under Order Na.2901087948_1 which expires
on 0912012014. and I9 not for resole.
User Notes: {1213612647)
§ 3.2 REVIEW OF CONTRACT DOCUMENTS AND FIELD CONDITIONS BY CONTRACTOR
§ 3.2.1 Execution of the Contract by the Contractor is a representation that the Contractor has visited the site, become
generally familiar with local conditions under which the Work is to be performed and correlated personal observations
with requirements of the Contract Documents,
§ 3.2.2 Because the Contract Documents are complementary, the Contractor shall, before starting each portion of the
Work, carefully study and compare the various Contract Documents relative to that portion of the Work, as well as the
information furnished by the Owner pursuant to Section 2.2.3, shall take field measurements of any existing
conditions related to that portion of the Work, and shall observe any conditions at the site affecting it. These
obligations are for the purpose of facilitating coordination and construction by the Contractor and are not for the
purpose of discovering errors, omissions, or inconsistencies in the Contract Documents, however, the Contractor shall
promptly report to the Architect any errors, inconsistencies or omissions discovered by or made known to the
Contractor as a request for information in such form as the Architect may require, It is recognized that the Contractor's
review is made in the Contractor's capacity as a contractor and not as a I icensed design professional, unless otherwise
specifically provided in the Contract Documents.
§ 3.2.3 The Contractor is not required to ascertain that the Contract Documents are in accordance with applicable laws,
statutes, ordinances, codes, rules and regulations, or lawful orders of public authorities, but the Contractor shall
promptly report to the Architect any nonconformity discovered by or made known to the Contractor as a request for
information in such form as the Architect may require,
§ 3.2.4 If the Contractor believes that additional cost or time is involved because of clarifications or instructions the
Architect issues in response to the Contractor's notices or requests for in formation pursuant to Sections 12.2 or 3.2.3,
the Contractor shall make Claims as provided in Article I S. If the Contractor Fails to perform the obligations of
Sections 3.2.2 or 3.2.3, the Contractor shall pay such costs and damages to the Owner as would have been avoided if
the Contractor had performed such obligations. If the Contractor performs those obligations, the Contractor shall not
be liable to the Owner or Architect for damages resulting from errors, inconsistencies or omissions in the Contract
Documents, For differences between field measurements or conditions and the Contract Documents, or for
nonconformities of the Contract Documents to applicable laws, statutes, ordinances, codes, rules and regulations, and
lawful orders of public authorities.
§ 3,3 SUPERVISION AND CONSTRUCTION PROCEDURES
§ 3.3.1 The Contractor shall supervise and direct the Work, using the Contractor's best skill and attention. The
Contractor shall be solely responsible for, and have control over, construction means, methods, techniques, sequences
and procedures and for coordinating all portions of the Work under the Contract, unless the Contract Documents give
other specific instructions concerning these matters. Ifthe Contract Documents give specific instructions concerning
construction means, methods, techniques, sequences or procedures, the Contractor shall evaluate the jobsite safety
thereof and, except as stated below, shall be fully and solely responsible for the jobsite safety of such means, methods,
techniques, sequences or procedures. If the Contractor determines that such means, methods, techniques, sequences or
procedures may not be safe, the Contractor shall give timely written notice to the Owner and Architect and shall not
proceed with that portion of the Work without further written instructions from the Architect. Ifthe Contractor is then
instructed to proceed with the required means, methods, techniques, sequences or procedures without acceptance of
changes proposed by the Contractor, the Owner shall be solely responsible for any loss or damage arising solely from
those Owner -required means, methods, techniques, sequences or procedures.
§ 3.3.2 The Contractor shall be responsible to the Owner for acts and omissions of the Contractor's employees,
Subcontractors and their agents and employees, and other persons or entities performing portions of the Work for, or
on behalf of, the Contractor or any of its Subcontractors.
§ 3.3.3 The Contractor shall be responsible for inspection of portions of Work already performed to determine that
such portions are in proper condition to receive subsequent Work.
§ 3.4 LABOR AND MATERIALS
§ 3.4.1 Unless otherwise provided in the Contract Documents, the Contractor shall provide and pay for labor,
materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation, and other
facilities and services necessary for proper execution and completion of the Work, whether temporary or permanent
and whether or not incorporated or to be incorporated in the Work.
Init AIA Document A201111 — 2007. Copyright O 1911, 1915. 1918. 1925, 19$7, 19$1, 19$8, 19$1, 19g3, 19813. 1970, 1975, 1957, 1997 end 2007 by The Ameficsn
Institute of Architects. All rights re9erved. WARNING; This AIA-0 Pocument is protected by U.S. Copyright Law and international Treatios. Unauthorized 92
reproduction ordistribution of this AIAA1 document, or any portion of It, may result In severe civil and criminal penalties, and will be prosecuted to the
maximum extent possible under the law. This document was produced by AIA software at 15:04:44 on 46A N2014 under Order No.2901087948_1 which expires
on 0912012014, and is not for resale.
User Notes: (1213612647)
§ 3.4.2 Except in the case of minor changes in the Work authorized by the Architect in accordance with Sections
3.12.8 or 7.4, the Contractor may make substitutions only with the consent of the Owner, after evaluation by the
Architect and in accordance with a Change Order or Construction Change Directive.
§ 3.4.3 The Contractor shall enforce strict discipline and good order among the Contractor's employees and other
persons carrying out the Work. The Contractor shall not permit employment of unfit persons or persons not properly
skilled in tasks assigned to them.
§ 3.5 WARRANTY
The Contractor warrants to the Owner and Architect that materials and equipment furnished under the Contract will be
of good quality and new unless the Contract Documents require or permit otherwise. The Contractor further warrants
that the Work will conform to the requirements of the Contract Documents and will be free from defects, except for
those inherent in the quality of the Work the Contract Documents require or permit. Work, materials, or equipment not
conforming to these requirements may be considered defective. The Contractor's warranty excludes remedy for
damage or defect caused by abuse, alterations to the Work not executed by the Contractor, improper or insufficient
maintenance, improper operation, or normal wear and tear and normal usage. Ifrequired by the Architect, the
Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment.
§ 3.6 TAXES
The Contractor shall pay sales, consumer, use and similar taxes for the Work provided by the Contractor that are
legally enacted when bids are received or negotiations concluded, whether or not yet effective or merely scheduled to
go into effect.
§ 3.7 PERMITS, FEES, NOTICES ANO COMPLIANCE WITH LAWS
§ 3.7.1 Unless otherwise provided in the Contract Documents, the Contractor shall secure and pay for the building
permit as well as for other permits, fees, licenses, and inspections by government agencies necessary for proper
execution and completion of the Work that are customarily secured after execution ofthe Contract and legally required
at the time bids are received or negotiations concluded.
§ 3.7.2 The Contractor shall comply with and live notices required by applicable laws, statutes, ordinances, codes,
rules and regulations, and lawful orders of public authorities applicable to performance of the Work.
§ 3.7,3 1 fthe Contractor performs Work knowing it to be contrary to applicable laws, statutes, ordinances, codes, rules
and regulations, or lawful orders of public authorities, the Contractor shall assume appropriate responsibility for such
Work and shall bear the costs attributable to correction.
§ 3.7,4 Concealed or Unknown Conditions. If the Contractor encounters conditions at the site that are (l) subsurface
or otherwise concealed physical conditions that dif cr materially from those indicated in the Contract Documents or
(2) unknown physical conditions of an unusual nature, that differ materially from those ordinarily found to exist and
generally recognized as inherent in construction activities ofthe character provided for in the Contract Documents, the
Contractor shall promptly provide notice to the Owner and the Architect before conditions are disturbed and in no
event later than 21 days after first observance ofthe conditions. The Architect will promptly investigate such
conditions and, if the Architect determines that they differ materially and cause an increase or decrease in the
Contractor's cost of, or time required for, performance of any part of the Work, will recommend an equitable
adjustment in the Contract Sum or Contract Time, or both. if the Architect determines that the conditions at the site are
not materially different from those indicated in the Contract Documents and that no change in the terms of the Contract
is justified, the Architect shall promptly notify the Owner and Contractor in writing, stating the reasons. If either party
disputes the Architect's determination or recommendation, that party may proceed as provided in Article 15.
§ 3.7.5 If, in the course of the Work, the Contractor encounters human remains or recognizes the existence of burial
markers, archaeological sites or wetlands not indicated in the Contract Documents, the Contractor shall immediately
suspend any operations that would affect them and shall notify the Owner and Architect. Upon receipt of such notice,
the Owner shall promptly take any action necessary to obtain governmental authorization required to resume the
operations. The Contractor shall continue to suspend such operations until otherwise instructed by the Owner but shall
continue with all other operations that do not affect those remains or features. Requests for adjustments in the Contract
Sum and Contract Time arising from the existence of such remains or features may be made as provided in Article 15.
A1A DCCum9nt A201'" — 200T. Copyright Q 1911, 1915, 1918, 1925, 1937, 1951, 1968. 1961, 1363. 1966, 1970, 1976, 1987. 1997 and 2007 by The American
InlL Institute of Architects. All rights reserved. WARNING: This AIA5 Document Is protected by U.S. Copyright Law and International Treatle5. Unauthorized 13
reproduction or ditirihutian of thI$ AW 000ument, or any portion or It, may result In severe civil and criminal penalties, and will be prosecuted to the
maximum extent possible under the law_ This document was produced by AIA software dt 15:04:44 on 0611012014 under Order No.2901087948_1 which expires
on M2412014, and is nut for resale,
User Notes, (1213512647)
§ 3.8 ALLOWANCES
§ 3.8.1 The Contractor shall include in the Contract Sum all allowances stated in the Contract Documents, Items
covered by allowances shall be supplied for such amounts and by such persons or entities as the Owner may direct, but
the Contractor shall not be required to employ persons or entities to whom the Contractor has reasonable objection,
§ 3,8,2 Unless otherwise provided in the Contract Documents,
.1 Allowances shall cover the cost to the Contractor of materials and equipment delivered at the site and
all required taxes, less applicable trade discounts;
.2 Contractor's costs for unloading and handling at the site, labor, installation costs, overhead, profit and
other expenses contemplated for stated allowance amounts shall be included in the Contract Sum but
not in the allowances; and
.3 Whenever costs are more than or less than allowances, the Contract Sum shall be adjusted accordingly
by Change Order, The amount of the Change Order shall reflect (1) the difference between actual costs
and the allowances under Section 3.8.2.1 and (2) changes in Contractor's costs under Section 3.8.2.2.
§ 3.8.3 Materials and equipment under an allowance shall be selected by the Owner with reasonable promptness.
§ 3.9 SUPERINTENDENT
§ 3.9.1 The Contractor shall employ a competent superintendent and necessary assistants who shall be in attendance at
the Project site during performance of the Work. The superintendent shall represent the Contractor, and
communications given to the superintendent shall be as binding as if given to the Contractor.
§ 3.9.2 The Contractor, as soon as practicable after award of the Contract, shall furnish in writing to the Owner
through the Architect the name and qualifications of proposed superintendent. The Architect may reply within 14
days to the Contractor in writing stating (1) whether the Owner or the Architect has reasonable objection to the
proposed superintendent or (2) that the Architect requires additional time to review. Failure of the Architect to reply
within the 14 day period shall constitute notice of no reasonable objection,
§ 3.9.3 The Contractor shall not employ a proposed superintendent to whom the Owner or Architect has made
reasonable and timely objection. The Contractor shall not change the superintendent without the Owner's consent,
which shall not unreasonably be withheld or delayed.
§ 3.10 CONTRACTOR'S CONSTRUCTION SCHEDULES
§ 3.10.1 The Contractor, promptly after being awarded the Contract, shall prepare and submit for the Owner's and
Architect's information a Contractor's construction schedule for the Work. The schedule shall not exceed time limits
current under the Contract Documents, shall be revised at appropriate intervals as required by the conditions of the
Work and Project, shall be related to the entire Project to the extent required by the Contract Documents, and shall
provide for expeditious and practicable execution of the Work.
§ 3.10.2 The Contractor shall prepare a submittal schedule, promptly after being awarded the Contract and thereafter
as necessary to maintain a current submittal schedule, and shall submit the schedule(s) for the Architect's approval.
The Architect's approval shall not unreasonably be delayed or withheld, The subminal schedule shall (1) be
coordinated with the Contractor's construction schedule, and (2) allow the Architect reasonable time to review
submittals. If the Contractor fails to submit a submittal schedule, the Contractor shall not be entitled to any increase in
Contract Sum or extension of Contract Time based on the time required for review of submittals.
§ 3.1D.3 The Contractor shall perform the Work in general accordance with the most recent schedules submitted to the
Owner and Architect,
§ 3,11 DOCUMENTS AND SAMPLES AT THE SITE
The Contractor shall maintain at the site for the Owner one copy of the drawings, Specifications, Addenda, Change
Orders and other Modifications, in good order and marked currently to indicate field changes and selections made
during construction, and one copy of approved Shop Drawings, Product Data, Samples and similar required
submittals. These shall be available to the Architect and shall be delivered to the Architect for submittal to the Owner
upon completion of the Work as a record of the Work as constructed.
Init. AIA Document A201 rM — 2007. Copyright Z 1911, 1915, 1918. 1925. 1937, 1951. 1958, 1961, 1903, 198$. 1970. 19'75, 1907, 1997 gno 2047 qy TheAm$fi0:PM
Institute of Architaets. All rights reegrvgd. WARNING: this AW Document IS protected by U.S. Copyright Law and International Treaties. Unauthorized 14
reproduction or distribution of this AIA11' Document, or any portion of It, may result In severe civil and criminal penalties, and will be prosecuted to the
j maximum extent possible under the law. T111s document was produced by AIA software at 15:04:44 on 0611012014 under Order No.2901007948_1 which expires
on 0912012014, and is not for resale.
User Notes., (1213612647)
§ 3.12 SWOP DRAWINGS, PRODUCT DATA AND SAMPLES
§ 3.12.1 Shop Drawings are drawings, diagrams, schedules and other data specially prepared for the Work by the
Contractor or a Subcontractor, Sub -subcontractor, manufacturer, supplier or distributor to illustrate some portion of
the Work.
§ 3.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and
other information furnished by the Contractor to illustrate materials or equipment for some portion of the Work.
§ 3.12.3 Samples are physical examples that illustrate materials, equipment or workmanship and establish standards
by which the Work will be judged,
§ 3.12.4 Shop Drawings, Product Data, Samples and similar submittals are not Contract Documents. Their purpose is
to demonstrate the way by which the Contractor proposes to conform to the information given and the design concept
expressed in the Contract Documents for those portions of the Work for which the Contract Documents require
submittals. Review by the Architect is subject to the limitations of Section 4.2.7. Informational submittals upon which
the Architect is not expected to take responsive action may be so identified in the Contract Documents. Submittals that
are not required by the Contract Documents may be returned by the Architect without action.
§ 3.12.5 The Contractor shall review for compliance with the Contract Documents, approve and submit to the
Architect Shop Drawings, Product Data, Samples and similar submittals required by the Contract Documents in
accordance with the submittal schedule approved by the Architect or, in the absence of at1 approved submittal
schedule, with reasonable promptness and in such sequence as to cause no delay in the Work or in the activities of the
Owner or of separate contractors,
§ 3,12,6 By submitting Shop Drawings, Product Data, Samples and similar submittals, the Contractor represents to the
Owner and Architect that the Contractor has (I ) reviewed and approved them, (2) determined and verified materials,
field measurements and field construction criteria related thereto, or will do so and (3) checked and coordinated the
information contained within such submittals with the requirements of the Work and of the Contract Documents.
§ 3.12.7 The Contractor shall perform no portion of the Work for which the Contract Documents require submittal and
review of Shop Drawings, Product data, Samples or similar submittals until the respective submittal has been
approved by the Architect.
§ 3.12.8 The Work shall be in accordance with approved submittals except that the Contractor shall not be relieved of
responsibility for deviations from requirements of the Contract Documents by the Architect's approval of Shop
Drawings, Product Data, Samples or similar submittals unless the Contractor has specifically informed the Architect
in writing of such deviation at the time of submittal and (1) the Architect has given written approval to the specific
deviation as a minor change in the Work, or (2) a Change Order or Construction Change Directive has been issued
authorizing the deviation, The Contractor shall not be relieved of responsibility for errors or omissions in Shop
Drawings, Product Data, Samples or similar submittals by the Architect's approval thereof.
§ 3.12.9 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data,
Samples or similar submittals, to revisions other than those requested by the Architect on previous submittals. In the
absence of such written notice, the Architect's approval of a resubmission shall not apply to such revisions.
§ 3,12.10 The Contractor shall not be required to provide professional services that constitute the practice of
architecture or engineering unless such services are specifically required by the Contract Documents for a portion of
the Worm or unless the Contractor needs to provide such services in order to carry out the Contractor's responsibilities
for construction means, methods, techniques, sequences and procedures. The Contractor shall not be required to
provide professional services in violation of applicable law. If professional design services or certifications by a
design professional related to systems, materials or equipment are specifically required of the Contractor by the
Contract Documents, the Owner and the Architect will specify all performance and design criteria that such services
must satisfy. The Contractor shall cause such services or certifications to be provided by a properly licensed design
professional, whose signature and seal shall appear on all drawings, calculations, specifications, certifications, Shop
Drawings and other submittals prepared by such professional. Shop Drawings and other submittals related to the Work
designed or certified by such professional, if prepared by others, shall bear such professional's written approval when
submitted to the Architect. The Owner and the Architect shall be entitled to rely upon the adequacy, accuracy and
Init. AIA Document A201 rM - 2007, Copyright* 1911, 19115, 1916, 1925, 1937. 1951, 1958. 1961, 1963, 1966. 1970, 1976, 1907. 1997 and 2007 by The American
Institute of Architeols. All rights reserved. WARNING: This AIA111 Document is protocted by U.S. Copyright Law and lntomational Treaties. Unauthorized .�
reproduction or distribution or this AlAt6 Document, or any portion of it, may result in severe clvlt and Criminal ponallies, and will be prosecuted to the
! maximum extent possible under the law. This document was produced by AIA software at 15:04:44 on OW1012014 under Order No.2941087948_1 which expires
vr1 t19120r2014, and ig not for r9saie,
User Notes: (121M12647)
completeness of the services, certifications and approvals performed or provided by such design professionals,
provided the Owner and Architect have specified to the Contractor all performance and design criteria that such
services must satisfy. Pursuant to this Section 3.12.10, the Architect will review, approve or take other appropriate
action on submittals only for the limited purpose of checking for conformance with information given and the design
concept expressed in the Contract Documents. The Contractor shall not be responsible for the adequacy of the
performance and design criteria specified in the Contract Documents.
§ 3.13 USE OF SITE;
The Contractor shall confine operations at the site to areas permitted by applicable laws, statutes, ordinances, codes,
rules and regulations, and lawful orders of public authorities and the Contract Documents and shall not unreasonably
encumber the site with materials or equipment.
§ 3.14 CUTTING AND PATCHING
§ 3.14.1 The Contractor shall be responsible for cutting, fitting or patching required to complete the Work or to make
its parts fit together properly. All areas requiring cutting, fitting and patching shall be restored to the condition existing
prior to the cutting, fitting and patching, unless otherwise required by the Contract Documents,
§ 3.14.2 The Contractor shall not damage or endanger a portion of the Work or tally or partially completed
construction of the Owner or separate contractors by cutting, patching or otherwise altering such construction, or by
excavation. The Contractor shall not out or otherwise alter such construction by the Owner or a separate contractor
except with written consent of the Owner and of such separate contractor; such consent shall not be unreasonably
withheld. The Contractor shall not unreasonably withhold from the Owner or a separate contractor the Contractor's
Consent to cutting or otherwise altering the Work,
§ 3.15 CLEANING UP
§ 3.15.1 The Contractor shall keep the premises and surrounding area free from accumulation of waste materials or
rubbish caused by operations under the Contract. At completion of the Work, the Contractor shall remove waste
materials, rubbish, the Contractor's tools, construction equipment, machinery and surplus materials from and about
the Project.
§ 3.15.2 If the Contractor fails to clean up as provided in the Contract Documents, the Owner may do so and Owner
shall be entitled to reimbursement from the Contractor.
§ 3.16 ACCESS TO WORK
The Contractor shall provide the Owner and Architect access to the Work in preparation and progress wherever
located.
g 3,17 ROYALTIES, PATENTS AND COPYRIGHTS
The Contractor shall pay all royalties and license fees. The Contractor shall defend suits or claims for infringement of
copyrights and patent rights and shall hold the Owner and Architect harmless from loss on account thereof, but shall
not be responsible for such defense or loss when a particular design, process or product of particular manufacturer or
manufacturers is required by the Contract Documents, or where the copyright violations are contained in Drawings,
Specifications or other documents prepared by the Owner or Architect. However, if the Contractor has reason to
believe that the required design, process or product is an infringement of copyright or a patent, the Contractor shall
be responsible For such loss unless such information is promptly furnished to the Architect.
§ 3.18INDEMNIFICATION
§ 3.18.1 To the fullest extent permitted by law the Contractor shall indemnify and hold harmless the Owner, Architect,
Architect's consultants, and agents and employees of any of them from and against claims, damages, losses and
expenses, including but not limited to attorneys' fees, arising out of or resulting from performance of the Work,
provided that such claim, damage, loss or expense is attributable to bodily injury, sickness, disease or death, or to
injury to or destruction of tangible property (other than the Work itself), but only to the extent caused by the negligent
acts or omissions of the Contractor, a Subcontractor, anyone directly or indirectly employed by them or anyone for
whose acts they may be liable, regardless of whether or not such claim, damage, loss or expense is caused in part by a
party indemnified hereunder. Such obligation shall not be construed to negate, abridge, or reduce other rights or
obligations of indemnity that would otherwise exist as to a party or person described in this Section 3.IS.
Ink Institute
Document A2011M — 2007. Copyright 0 1911. 1916. 1918, 1926, 1931, 1961. 1958. 1961, 1963, 1988, 1970, 1976, 1987. 1997 and 2007 by The American
Institute of Architects. All rights reserved. WARNING; This AW Document is protected by U.S. copyright Law and Intornational Troatios. Unauthorized 1
reproduction or distribution of this AIA* Document, or any portion of It, may result In severe civil and Criminal penalties, an@ will he prosecuted to the
f maximum extent passible underthe law. Thisdocument was produced byAIA softwareat 1&04:44 on OW1012014 under Order No.2941087948_1 which expires
on 09120l2014. and Is not for resale.
User Notes, (1213612647)
§ 3.18.2 In claims against any person or entity indemnified under this Section 3.18 by an employee of the Contractor,
a Subcontractor, anyone directly or indirectly employed by them or anyone for whose acts they may be liable, the
indemnification obligation under Section 3.18.1 shall not be limited by a limitation on amount or type of damages,
compensation or benefits payable by or for the Contractor or a Subcontractor under workers' compensation acts,
disability benefit acts or other employee benefit acts.
ARTICLE 4 ARCHITECT
§ 4,1 GENERAL
§ 4.1.1 The Owner shall retain an architect lawfully licensed to practice architecture or an entity lawfully practicing
architecture in the jurisdiction where the Project is located. Thai person or entity is identified as the Architect in the
Agreement and is referred to throughout the Contract Documents as if singular in number.
§ 4.1.2 Duties, responsibilities and limitations ofauthority ofthe Architect as set forth in (lie Contract Documents shall
not be restricted, modified or extended without written consent of the Owner, Contractor and Architect. Consent shall
not be unreasonably withheld.
§ 4.1.3 If the employment of the Architect is terminated, the Owner shall employ a successor architect as to whom the
Contractor has no reasonable objection and whose status under the Contract Documents shall be that of the Architect.
g 4.2 ADMINISTRATION OF THE CONTRACT
§ 4.2.1 The Architect will provide administration of the Contract as described in the Contract Documents and will be
an Owner's representative during construction until the date the Architect issues the final Certificate for Payment. The
Architect will have authority to act on behalf of the Owner only to the extent provided in the Contract Documents.
§ 4.2.2 The Architect will visit the site at intervals appropriate to the stage of construction, or as otherwise agreed with
the owner, to become generally familiar with the progress and quality of the portion ofthe Work completed, and to
determine in general if the Work observed is being performed in a manner indicating that the Work, when fully
completed, will be in accordance with the Contract Documents. However, the Architect will not be required to make
exhaustive or continuous on -site inspections to check the quality or quantity of the Work. The Architect will not have
control over, charge of or responsibility for, the construction means, methods, techniques, sequences or procedures, or
for the safety precautions and programs in connection with the Work, since these are solely the Contractor's rights and
responsibilities under the Contract Documents, except as provided in Section 3.3.1.
§ 4.2.3 On the basis of the site visits, the Architect will keep the Owner reasonably informed about the progress and
quality of the portion ofthe Work completed, and report to the Owner ( 1) known deviations from the Contract
Documents and from the most recent construction schedule submitted by the Contractor, and (2) defects and
deficiencies observed in the Work. The Architect will not be responsible for the Contractor's failure to perform the
Work in accordance with the requirements of the Contract Documents. The Architect will not have control over or
charge of and will not be responsible for acts or omissions of the Contractor, Subcontractors, or their agents or
employees, or any other persons or entities performing portions of the Work.
§ 4.2.4 COMMUNICATIONS FACILITATING CONTRACT ADMINISTRATION
Except as otherwise provided in the Contract Documents or when direct communications have been specially
authorized, the Owner and Contractor shall endeavor to communicate with each other through the Architect about
matters arising out of or relating to the Contract. Communications by and with the Architect's consultants shall be
through the Architect. Communications by and with Subcontractors and material suppliers shall be through the
Contractor. Communications by and with separate contractors shall be through the Owner.
§ 4.2.6 Based on the Architect's evaluations of the Contractor's Applications for Payment, the Architect will review
and certify the amounts due the Contractor and will issue Certificates for Payment in such amounts.
§ 4.2.6 The Architect has authority to reject Work that does not conform to the Contract Documents. Whenever the
Architect considers it necessary or advisable, the Architect will have authority to require inspection or testing of the
Work in accordance with Sections 13.5.2 and 13.5.3, whether or not such Work is fabricated, installed or completed.
However, neither this authority of the Architect nor a decision made in good faith either to exercise or not to exercise
such authority shall give rise to a duty or responsibility of the Architect to the Contractor, Subcontractors, material and
equipment suppliers, their agents or employees, or other persons or entities performing portions of the Work.
Init.AIA Document A201 TM — 2007. Copyright 01911, 1915, 1918. 1025, 1937, 1951. 1958. 1961, 1963. 1966, 1970. 1976. 1987, 1997 and 2007 by The ,American
Institute of Archileats. All rights reserved. WARNING. This AIA00 Document is protected by U.S. Copyright Law and Intonational Troatias. Unauthorizod 1)�
reproduction or distribution of this AIA"' Document, or any portion of It, may result In severe civil and criminal penalties, and will he pr*seculod to the
f maximum extent possible under the law. This document was produced by AIA software at 15:04,44 on 0611W2014 under Order No.2901087948_1 which expires
on 0912012014. and Is not for resale.
User Notes: (1213612647)
§ 4.2.7 The Architect will review and approve, or take other appropriate action upon, the Contractor's submittals such
as Shop Drawings, Product Data and Samples, but only for the limited purpose of ehecking for conformance with
information given and the design concept expressed in the Contract Documents. The Architect's action will be taken
in accordance with the submittal schedule approved by the Architect or, in the absence of an approved submittal
schedule, with reasonable promptness while allowing sufficient time in the Architect's professional judgment to
permit adequate review. Review of such submittals is not conducted for the purpose of determining the accuracy and
completeness of other details such as dimensions and quantities, or for substantiating instructions for installation or
performance of equipment or systems, all of which remain the responsibility of the Contractor as required by the
Contract Documents. The Architect's review of the Contractor's submittals shall not relieve the Contractor of the
obligations under Sections 3.3, 3.5 and 3.12. The Architect's review shall not constitute approval of safety precautions
or, unless otherwise specifically stated by the Architect" of any construction means, methods, techniques, sequences or
procedures. The Architect's approval of a specific item shall not indicate approval of an assembly of which the item is
a component.
§ 4.2.8 The Architect will prepare Change Orders and Construction Change Directives, and may authorize minor
changes in the Work as provided in Section 7.4. The Architect will investigate and make determinations and
recommendations regarding concealed and unknown conditions as provided in Section 3.7.4.
§ 4.2.9 The Architect will conduct inspections to determine the date or dates of Substantial Completion and the date of
final completion; issue Certificates of Substantial Completion pursuant to Section 9,8; receive and forward to the
Owner, for the Owner's review and records, written warranties and related documents required by the Contract and
assembled by the Contractor pursuant to Section 9.10; and issue a final Certificate for Payment pursuant to Section
9.10.
§ 4.2.10 If the Owner and Architect agree, the Architect will provide one or more project representatives to assist in
carrying out the Architect's responsibilities at the site. The duties, responsibilities and limitations of authority of such
project representatives shall be as set forth in an exhibit to be incorporated in the Contract Documents.
§ 4.2.11 The Architect will interpret and decide matters concerning performance under, and requirements of, the
Contract Documents on written request of either the Owner or Contractor. The Architect's response to such requests
will be made in writing within any time limits agreed upon or otherwise with reasonable promptness.
§ 4.2.12 Interpretations and decisions of the Architect will be consistent with the intent of, and reasonably inferable
from, the Contract Documents and will be in writing or in the form of drawings. When making such interpretations and
decisions, the Architect will endeavor to secure faithful performance by both Owner and Contractor, will not show
partiality to either and will not be liable for results of interpretations or decisions rendered in good faith.
f 4.2.13 The Architect's decisions on matters relating to aesthetic effect will be final if consistent with the intent
expressed in the Contract Documents.
§ 4.2.14 The Architect will review and respond to requests for information about the Contract Documents. The
Architect's response to such requests will be made in writing within any time limits agreed upon or otherwise with
reasonable promptness. If appropriate, the Architect will prepare and issue supplemental Drawings and Specifications
in response to the requests for information.
ARTICLE 5 SUBCONTRACTORS
§ 5.1 DEFINITIONS
§ 5.1.1 A Subcontractor is a person or entity who has a direct contract with the Contractor to perform a portion of the
Work at the site. The term "Subcontractor" is referred to throughout the Contract Documents as if singular in number
and means a Subcontractor or an authorized representative of the Subcontractor. The term "Subcontractor" does not
include a separate contractor or subcontractors of a separate contractor.
§ 5.1.2 A Sub -subcontractor is a person or entity who has a direct or indirect contract with a Subcontractor to perform
a portion of the Work at the site. The term "Sub -subcontractor" is referred to throughout the Contract Documents as if
singular in number and means a Sub -subcontractor or an authorized representative of the Sub -subcontractor.
AIA Document A201 rM - 2007. Copyright Q 1911. 1915, 1918, 1925, 1937, 1951, 1958, 1961, t963, 1966, 1970, 1976. 1987, 1997 and 2007 by The American
tnl#" Institute of Architects. All rights reserved. WARNING: This AIA,1' Document Is protected by U.S. Copyright Law arid International Treatles. UnaGthgri;gd �$
reproduction or distribution of this AIAI Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosocutod to the
maximum oxtent possible under tha law. This document was produced by AIA software al 15:04:44 on 0611012014 under Order No,2901007948_1 which expires
on 09120/2014. and Is not for resale.
User Notes. (12136126471
§ 5.2 AWARD OF SUBCONTRACTS AND OTHER CONTRACTS FOR PORTIONS OF THE WORK
§ 5.2.1 Unless otherwise stated in the Contract Documents or the bidding requirements, the Contractor, as soon as
practicable alter award of the Contract, shall furnish in writing to the Owner through the Architect the names of
persons or entities (including those who are to furnish materials or equipment fabricated to a special design) proposed
for each principal portion of the Work. The Architect may reply within 14 days to the Contractor in writing stating (1)
whether the Owner or the Architect has reasonable objection to any such proposed person or entity or (2) that the
Architect requires additional time for review. Failure of the Owner or Architect to reply within the 14-day period shall
constitute notice of no reasonable objection.
§ 5.2.2 The Contractor shall not contract with a proposed person or entity to whom the Owner or Architect has made
reasonable and timely objection. The Contractor shall not be required to contract with anyone to whom the Contractor
has made reasonable objection.
§ 5,2.3 1 f the Owner or Architect has reasonable objection to a person or entity proposed by the Contractor, the
Contractor shall propose another to whom the Owner or Architect has no reasonable objection. If the proposed but
rejected Subcontractor was reasonably capable of performing the Work, the Contract Sum and Contract Time shall be
increased or decreased by the difference, if any, occasioned by such change, and an appropriate Change Order shall be
issued before commencement of the substitute Subcontractor's Work, I-lowever, no increase in the Contract Sum or
Contract Time shall be allowed for such change unless the Contractor has acted promptly and responsively in
submitting names as required.
§ 5.2.4 The Contractor shall not substitute a Subcontractor, person or entity previously selected if the Owner or
Architect makes reasonable objection to such substitution.
§ 5.3 SUBCONTRACTUAL RELATIONS
By appropriate agreement, written where legally required for validity, the Contractor shall require each Subcontractor,
to the extent of the Work to be performed by the Subcontractor, to he bound to the Contractor by terms of the Contract
Documents, and to assume toward the Contractor all the obligations and responsibilities, including the responsibility
for safety of the Subcontractor's Work, which the Contractor, by these Documents, assumes toward the Owner and
Architect. Each subcontract agreement shall preserve and protect the rights of the Owner and Architect under the
Contract Documents with respect to the Work to be performed by the Subcontractor so that subcontracting thereof will
not prejudice such rights, and shall allow to the Subcontractor, unless specifically provided otherwise in the
subcontract agreement, the benefit of all rights, remedies and redress against the Contractor that the Contractor, by the
Contract Documents, has against the Owner. Where appropriate, the Contractor shall require each Subcontractor to
enter into similar agreements with Sub -subcontractors. The Contractor shall make available to each proposed
Subcontractor, prior to the execution of the subcontract agreement, copies of the Contract Documents to which the
Subcontractor will be bound, and, upon written request of the Subcontractor, identify to the Subcontractor terms and
conditions of the proposed subcontract agreement that may be at variance with the Contract Documents.
Subcontractors will similarly make copies of applicable portions of such documents available to their respective
proposed Sub -subcontractors.
§ 5.4 CONTINGENT ASSIGNMENT OF SUBCONTRACTS
§ 5.4.1 Each subcontract agreement for a portion of the Work is assigned by the Contractor to the Owner, provided that
A assignment is effective only after termination of the Contract by the Owner for cause pursuant to
Section 14.2 and only for those subcontract agreements that the Owner accepts by notifying the
Subcontractor and Contractor in writing, and
.2 assignment is subject to the prior rights of the surety, if any, obligated under bond relating to the
Contract.
When the Owner accepts the assignment of a subcontract agreement, the Owner assumes the Contractor's rights and
obligations under the subcontract.
§ 5.4.2 Upon such assignment, if die Work has been suspended for more than 30 days, the Subcontractor's
compensation shall be equitably adjusted for increases in cost resulting from the suspension.
§ 5.4.3 Upon such assignment to the Owner under this Section 5.4, the Owner may further assign the subcontract to a
successor contractor or other entity. If the Owner assigns the subcontract to a successor contractor or other entity, the
Init. AIA Doeumant A2Qi I"— 2007, Copyright O 1911, 1915, 1918, 1925, 1937, 1951, 1958, 1961. 1963, 1966, 1970. 1976. 1987, 1997 and 2007 by The American
InsMuto of ArChiteCls, All rigrita reserved, WARNING. This AIA® Document Is protected by U.S. Copyright Law and International Treaties. Unauthorised 1
reproduction or distribution of this AM' Document, or any poetlon of it, may rosult in severe 41vll and criminal penalties, and will be prosecuted to the
maximum extent possible under the law. This document was produced by AIA software at 15:04:44 on 05110/2014 under Grder No.2901087948_1 wNCh expirea
on 09l21712014, and to not tar resaie.
User Notes: (1213612647)
Owner shall nevertheless remain legally responsible for all of the successor contractor's obligations under the
subcontract.
ARTICLE 6 CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS
§ 6.1 OWNER'S RIGHT TO PERFORM CONSTRUCTION AND TO AWARD SEPARATE CONTRACTS
§ 6.1.1 The Owner reserves the right to perform construction or operations related to the Project with the Owner's own
forces, and to award separate contracts in connection with other portions of the Project or other construction or
operations on the site under Conditions of the Contract identical or substantially similar to these including those
portions related to insurance and waiver of subrogation. If the Contractor claims that delay or additional cost is
involved because of such action by the Owner, the Contractor shall make such Claim as provided in Article 15.
§ 6.1.2 When separate contracts are awarded for different portions of the Project or other construction or operations on
the site, the term "Contractor" in the Contract Documents in each case shall mean the Contractor who executes each
separate Owner -Contractor Agreement.
§ 6.1.3 The Owner shall provide for coordination of the activities of the Owner's own forces and of each separate
contractor with the Work ofthe Contractor, who shall cooperate with them. The Contractor shall participate with other
separate contractors and the Owner in reviewing their construction schedules. `rhe Contractor shall make any revisions
to the construction schedule deemed necessary after a joint review and mutual agreement. The construction schedules
shal I then constitute the schedules to be used by the Contractor, separate contractors and the Owner until subsequently
revised.
§ 6.1.4 Unless otherwise provided in the Contract Documents, when the Owner performs construction or operations
related to the Project with the Owner's own forces, the Owner shall be deerned to be subject to the same obligations
and to have the same rights that apply to the Contractor under the Conditions of the Contract, including, without
excluding others, those stated in Article 3, this Article 6 and Articles 10, 11 and 12.
§ 6.2 MUTUAL RESPONSIBILITY
§ 6.2.1 The Contractor shall afford the Owner and separate contractors reasonable opportunity for introduction and
storage of their materials and equipment and performance of their activities, and shall connect and coordinate the
Contractor's construction and operations with theirs as required by the Contract Documents.
§ 6.2.2 Ifpart of the Contractor's Work depends for proper execution or results upon construction or operations by the
Owner or a separate contractor, the Contractor shall, prior to proceeding with that portion ofthe Work, promptly report
to the Architect apparent discrepancies or defects in such other construction that would render it unsuitable for such
proper execution and results. Failure of the Contractor so to report shall constitute an acknowledgment that the
Owner's or separate contractor's completed or partially completed construction is fit and proper to receive the
Contractor's Work, except as to defects not then reasonably discoverable.
§ 6.2.3 The Contractor shall reimburse the Owner for costs the Owner incurs that are payable to a separate contractor
because of the Contractor's delays, improperly timed activities or defective construction. The Owner shall be
responsible to the Contractor for costs the Contractor incurs because of a separate contractor's delays, improperly
tinted activities, damage to the Work or defective construction.
§ 6.2.4 The Contractor shall promptly remedy damage the Contractor wrongfully causes to completed or partially
completed construction or to property of the Owner or separate contractors as provided in Section 10.2.5,
§ 6.2.5 The Owner and each separate contractor shall have the same responsibilities for cutting and patching as are
described for the Contractor in Section 3.14.
§ 6.3 OWNER'S RIGHT TO CLEAN UP
If a dispute arises among the Contractor, separate contractors and the Owner as to the responsibility under their
respective contracts for maintaining the premises and surrounding area free from waste materials and rubbish, the
Owner may clean up and the Architect will allocate the cost among those responsible.
Init. AIA Document A201 r* — 2U47. Copyright 0 1911, 1915. 1918, 1925. 1937. 1951, 1958, 1961. 1963, 1966. 1970, 1976, 1987, 1997 and 2007 by The American
Institute of ArChitecis. All rights reserved. WARNING: This AIA1' document is protected by U.B. Copyright Law and International Treatles. Unauthorized ��
reproduction or distribution of this ALAI Document, or any portion of R. may result in severe clvll and criminal penalties, and will he prosecuted to the
r maximum extent possible undo( the law. This document was produced by AtA soflware at 15:04:44 6n W1012014 under 04-dar No 29C 1087948_1 which expires
on 09I2012014, and is not for resale.
User Notes: (1213612647)
ARTICLE 7 CHANGES IN THE WORK
§ 7.1 GENERAL
§ 7.1.1 Changes in the Work may be accomplished after execution of the Contract, and without invalidating the
Contract, by Change Order, Construction Change Directive or order for a minor change in the Work, subject to the
limitations stated in this Article 7 and elsewhere in the Contract Documents.
§ 7.1.2 A Change Order shall be based upon agreement among the Owner, Contractor and Architect; a Construction
Change Directive requires agreement by the Owner and Architect and may or may not be agreed to by the Contractor;
an order for a minor change in the Work may be issued by the Architect alone.
§ 7.1.3 Changes in the Work shall be performed under applicable provisions ofthe Contract Documents, and the
Contractor shall proceed promptly, unless otherwise provided in the Change Order, Construction Change Directive or
order for a minor change in the Work,
§ 7.2 CHANGE ORDERS
§ 7.2.1 A Change Order is a written instrument prepared by the Architect and signed by the Owner, Contractor and
Architect stating their agreement upon all of the following:
.1 The change in the Work;
.2 The amount of the adjustment, if any, in the Contract Sum; and
.3 The extent of the adjustment, if any, in the Contract Time,
§ 7.3 CONSTRUCTION CHANGE DIRECTIVES
§ 7.3.1 A Construction Change Directive is a written order prepared by the Architect and signed by the Owner and
Architect, directing a change in the Work prior to agreement on adjustment, if any, in the Contract Sum or Contract
Time, or both. The Owner may by Construction Change Directive, without invalidating the Contract, order changes in
the Work within the general scope of the Contract consisting of additions, deletions or other revisions, the Contract
Sum and Contract Time being adjusted accordingly.
§ 7.3.2 A Construction Change Directive shall be used in the absence of total agreement on the terms of a Change
Order.
§ 7.3.3 1 f the Construction Change Directive provides for an adjustment to the Contract Sum, the adjustment shall be
based on one of the following methods:
.1 Mutual acceptance ofa lump sum properly itemized and supported by sufficient substantiating data to
permit evaluation;
.2 Unit prices stated in the Contract Documents or subsequently agreed upon;
.3 Cost to be determined in a manner agreed upon by the parties and a mutually acceptable fixed or
percentage fee; or
.4 As provided in Section 7.3.7.
§ 7.3.4 If unit prices are stated in the Contract Documents or subsequently agreed upon, and if quantities originally
contemplated are materially changed in a proposed Change Order or Construction Change Directive so that
application of such unit prices to quantities of Work proposed will cause substantial inequity to the Owner or
Contractor, the applicable unit prices shall be equitably adjusted,
§ 7.3.5 Upon receipt of Construction Change Directive, the Contractor shall promptly proceed with the change in the
Work involved and advise the Architect of the Contractor's agreement or disagreement with the method, if any,
provided in the Construction Change Directive for determining the proposed adjustment in the Contract Sum or
Contract Time,
§ 7.3.6 A Construction Change Directive signed by the Contractor indicates the Contractor's agreement therewith,
including adjustment in Contract Sum and Contract Time or the method for determining them. Such agreement shall
be effective immediately and shall be recorded as a Change Order,
§ 1.3.7 1 f the Contractor does not respond promptly or disagrees with the method for adjustment in the Contract Sum,
the Architect shall determine the method and the adjustment on the basis of reasonable expenditures and savings of
those performing; the Work attributable to the change, including, in case of an increase in the Contract Sum, an amount
Init. AIA document A201 rM — 2007. Copyright Z 1911, 1915, 1418, 1925, 1937. 1951, 1950, 1961, 1963, 1966. 1970, 1976. 1987, 1997 and 2007 by The American
institute of Archilecls. All rights reserved, WARNING{; This AIA1 Document Is protected by U.S. Copyright Law and Inlemationaf Treaties. unauthorized 2!�
reproduction Qr distribution of this AIA Document. or any portion of It, may result in severe civil and criminal penattles, and will be prosecuted to the
j maximum extent paesible under the law. This document was produced by AIA software at 15:04:44 on 0611012014 under Order No, 2901087948-1 which expires
on 09120l2014, and is not for resale.
User Notes; (1213612647)
for overhead and profit as set Forth in the Agreement, or if no such amount is set forth in the Agreement, a reasonable
amount. In such case, and also under Section 7.3.3.3, the Contractor shall keep and present, in such form as the
Architect may prescribe, an itemized accounting together with appropriate supporting data. Unless otherwise provided
in the Contract Documents, costs for the purposes of this Section 7.3.7 shall be limited to the following:
1 Costs of labor, including social Security, old age and unemployment insurance, fringe benefits required
by agreement or custom, and workers' compensation insurance;
,2 Costs of materials, supplies and equipment, including cost of transportation, whether incorporated or
consumed;
.3 Rental costs of machinery and equipment, exclusive of hand tools, whether rented from the Contractor
or others;
,4 Costs of premiums for all bonds and insurance, permit fees, and sales, use or similar taxes related to the
Work; and
,5 Additional costs of supervision and field office personnel directly attributable to the change,
§ 7.3.8 The amount of credit to be allowed by the Contractor to the Owner for a deletion or change that results in a net
decrease in the Contract Sum shall be actual net cost as confirmed by the Architect. When both additions and credits
covering related Work or substitutions are involved in a change, the allowance for overhead and profit shall be figured
on the basis of net increase, if any, with respect To that change,
§ 7.3.9 Pending final determination of the total cost of a Construction Change Directive to the Owner, the Contractor
may request payment for Work completed under the Construction Change Directive in Applications for Payment. The
Architect will make an interim determination for purposes of monthly certification for payment for those costs and
certify for payment the amount that the Architect determines, in the Architect's professional judgment, to be
reasonably justified. The Architect's interim determination of cost shall adjust the Contract Sum on the same basis as
a Change Order, subject to the right of either party to disagree and assert a Claim in accordance with Article 15.
§ 7.3.10 When the Owner and Contractor agree with a determination made by the Architect concerning the
adjustments in the Contract Sum and Contract Time, or otherwise reach agreement upon the adjustments, such
agreement shall be effective immediately and the Architect will prepare a Change Order. Change Orders may be
issued for all or any part of a Construction Change Directive,
§ 7A MINOR CHANGES IN THE WORK
The Architect has authority to order minor changes in the Work not involving adjustment in the Contract Sum or
extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes will be
effected by written order signed by the Architect and shall be binding on the Owner and Contractor,
ARTICLE 8 TIME
§ 81 DEFINITIONS
§ 8.1.1 Unless otherwise provided, Contract Time is the period of time, including authorized adjustments, allotted in
the Contract Documents for Substantial Completion of the Work.
§ 8.1.2 The date of commencement of the Work is the date established in the Agreement.
§ 8.1.3 The date of Substantial Completion is the date certified by the Architect in accordance with Section 9.8.
§ 8.1.4 The term "day" as used in the Contract Documents shall mean calendar day unless otherwise specifically
defined.
§ 8.2 PROGRESS AND COMPLETION
§ 8.2.1 Time I imits stated in the Contract Documents are of the essence of the Contract. By executing the Agreement
the Contractor confirms that the Contract "rime is a reasonable period for performing the Work.
§ 8.2.2 The Contractor shall not knowingly, except by agreement or instruction of the Owner in writing, prematurely
commence operations on the site or elsewhere prior to the effective date of insurance required by Article 1 1 to be
furnished by the Contractor and Owner. The date of commencement of the Work shall not be changed by The effective
date of such insurance,
last AIA Qocumant A2011m — 2007, Copyright* 1911, 1915, 1910, 1925. 1937. 1951, 1958. 1961, 1963, 1966, 1970. 1976, 1967, 1997 and 2007 by The American
In5til0e of Archilects. All rights reserved, WARNING: This AIA1 Document is protected by U.S. Copyright Law and international Treaties, unauthorized
reproduction or distribution of this A AIA Document, or arty portion of it, may result In severe civil and criminal penalties, and will be prosecuted to the 22
f maximum extent possible under the law. This document was produced by AIA aoflware at 16:04:44 on 0511612o14 under Order No.2901087948_1 whirll expires
4n 09I2012014, and i8 not for re9ele,
User Notes: (1213612647)
§ 8.2.3 The Contractor shall proceed expeditiously with adequate forces and shall achieve Substantial Completion
within the Contract Time.
§ 8,3 DELAYS AND EXTENSIONS OF TIME
§ 811 If the Contractor is delayed at any time in the commencement or progress oFthe Work by an act or neglect of
the Owner or Architect, or of an employee of either, or of a separate contractor employed by the Owner; or by changes
ordered in the Work, or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes
beyond the Contractor's control; or by delay authorized by the Owner pending mediation and arbitration; or by other
causes that the Architect determines may justify delay, then the Contract Time shall be extended by Change Order for
such reasonable tiine as the Architect may determine.
§ 8.3.2 Claims relating to time shall be made in accordance with applicable provisions of Article 15.
§ 8.3.3 This Section 8.3 does not preclude recovery of damages for delay by either party under other provisions of the
Contract Documents.
ARTICLE 9 PAYMENTS AND COMPLETION
§ 9.1 CONTRACT SUM
The Contract Sum is stated in the Agreement and, including authorized adiustments, is the total amount payable by the
Owner to the Contractor for performance of the Work under the Contract Documents.
§ 9.2 SCHEDULE OF VALUES
Where the Contract is based on a stipulated sum or Guaranteed Maximum Price, the Contractor shall submit to the
Architect, before the first Application for Payment, a schedule of values allocating the entire Contract Sum to the
various portions of the Work and prepared in such form and supported by such data to substantiate its accuracy as the
Architect may require. This schedule, unless objected to by the Architect, shall be used as a basis for reviewing the
Contractor's Applications far Payment.
§ 9,3 APPLICATIONS FOR PAYMENT
§ 9,3,1 At least ten days before the date established for each progress payment, the Contractor shall submit to the
Architect an itemized Application for Payment prepared in accordance with the schedule of values, if required under
Section 9.2, for completed portions of the Work. Such application shall be notarized, if required, and supported by
such data substantiating the Contractor's right to payment as the Owner or Architect may require, such as copies of
requisitions from Subcontractors and material suppliers, and shall reflect retainage if provided for in the Contract
Documents.
§ 93,1.1 As provided in Section 7.3.9, such applications may include requests for payment on account of changes in
the Work that have been properly authorized by Construction Change Directives, or by interim determinations of the
Architect, but not yet included in Change Orders.
§ 9.3.1.2 Applications for Payment shall not include requests for payment for portions of the Work for which the
Contractor does not intend to pay a Subcontractor or material supplier, unless such Work has been performed by others
whom the Contractor intends to pay.
§ 9.3,2 Unless otherwise provided in the Contract Documents, payments shall be made on account of materials and
equipment delivered and suitably stored at the site for subsequent incorporation in the Work. Ifapproved in advance
by the Owner, payment may similarly be made for materials and equipment suitably stored off the site at a location
agreed upon in writing. Payment for materials and equipment stored on or off the site shall be conditioned upon
compliance by the Contractor with procedures satisfactory to the Owner to establish the Owner's title to such materials
and equipment or otherwise protect the Owner's interest, and shall include the costs of applicable insurance, storage
and transportation to the site for such materials and equipment stored off the site.
§ 9.3,3 The Contractor warrants that tide to all Work covered by an Application for Payment will pass to the Owner no
later than the time of payment. The Contractor further warrants that upon submittal of an Application for Payment all
Work for which Certificates for Payment have been previously issued and payments received From the Owner shall, to
the best of the Contractor's knowledge, information and belief, be free and clear of liens, claims, security interests or
Intt AIA Document A201 Ta — 2007. copyright C 1911. 1915, 1916, 1925. 1937, 1951, 1958. 1961, 1963. 1966, 1970, 1976, 1987. 1997 arid 2007 by The American
tg8tituteof Arehitecls. All rights reserved. WARNING: This Al A" Document Is protocted by U.S. Copyright Law and Intematlonal Treaties. Unauthorized 23
reproduction or distribution of this AIA' ❑acumant, or any portion or It, may result In severe civil and grlminal penalties, and will be prosecuted to the
1 maximum extent possible tinder the law. This document was produced by AIA software at 15;04,44 on 08l1012014 under order No.21301087949_11 which expires
on 0912012014, and is pot for ra$ale.
User Notes: {1213612647)
encumbrances in favor of the Contractor, Subcontractors, material suppliers, or other persons or entities making a
claim by reason of having provided labor, materials and equipment relating to the Work.
§ 9.4 CERTIFICATES FOR PAYMENT
§ 9.4.1 The Architect will, within seven days after receipt of the Contractor's Application for Payment, either issue to
the Owner a Certificate for Payment, with a copy to the Contractor, For such amount as the Architect determines is
properly due, or notify the Contractor and Owner in writing of the Architect's reasons for withholding ecrtification in
whole or in part as provided in Section 9.5.1.
§ 9.4.2 The issuance of Certificate for Payment will constitute a representation by the Architect to the Owner, based
on the Architect's evaluation of the Work and the data comprising the Application for Payment, that, to the best of the
Architect's knowledge, information and belief, the Work has progressed to the point indicated and that the quality of
the Work is in accordance with the Contract Documents. The foregoing representations are subject to an evaluation of
the Work for conformance with the Contract Documents upon Substantial Completion, to results of subsequent tests
and inspections, to correction of minor deviations from the Contract Documents prior to completion and to specific
qualifications expressed by the Architect. The issuance ofa Certificate for Payment will further constitute a
representation that the Contractor is entitled to payment in the amount certified. However, the issuance of Certificate
for Payment will not be a representation that the Architect has ( 1) made exhaustive or continuous on -site inspections to
check the quality or quantity of the Work, (2) reviewed construction means, methods, techniques, sequences or
procedures, (3) reviewed copies of requisitions received from Subcontractors and material suppliers and other data
requested by the Owner to substantiate the Contractor's right to payment, or (4) made examination to ascertain how or
for what purpose the Contractor has used money previously paid on account of the Contract Sum.
§ 9.5 DECISIONS TO WITHHOLD CERTIFICATION
§ 9.5.1 The Architect may withhold a Certificate for Payment in whole or in part, to the extent reasonably necessary to
protect the Owner, if in the Architect's opinion the representations to the Owner required by Section 9.4.2 cannot be
made. If the Architect is unable to certify payment in the amount of the Application, the Architect will notify the
Contractor and Owner as provided in Section 9.4.1. If the Contractor and Architect cannot agree on a revised amount,
the Architect will promptly issue a Certificate For Payment for the amount for which the Architect is able to make such
representations to the Owner. The Architect may also withhold a Certificate for Payment or, because of subsequently
discovered evidence, may nullify the whole or a part of a Certificate For Payment previously issued. to such extent as
may be necessary in the Architect's opinion to protect the Owner from loss for which the Contractor is responsible,
including loss resulting from acts and omissions described in Section 3.3.2, because of
.1 defective Work not remedied;
.2 third party claims filed or reasonable evidence indicating probable filing of such claims unless security
acceptable to the Owner is provided by the Contractor;
.3 failure of the Contractor to make payments properly to Subcontractors or for labor, materials or
equipment;
.4 reasonable evidence that the Work cannot be completed for the unpaid balance of the Contract Sum;
.5 damage to the Owner or a separate contractor;
.6 reasonable evidence that the Work will not be completed within the Contract Time, and that the unpaid
balance would not be adequate to cover actual or liquidated damages for the anticipated delay; or
.7 repeated failure to carry out the Work in accordance with the Contract Documents.
§ 9.6.2 When the above reasons for withholding certification are removed, certification will be made for amounts
previously withheld.
§ 9.5.3 If the Architect withholds certification for payment under Section 9.5.1.3, the Owner may, at its sale option,
issue joint checks to the Contractor and to any Subcontractor or material or equipment suppliers to whom the
Contractor tailed to make payment for Work properly performed or material or equipment suitably delivered. If the
Owner makes payments by joint check, the Owner shall notify the Architect and the Architect will reflect such
payment on the next Certificate for Payment.
§ 9.6 PROGRESS PAYMENTS
§ 9.6.1 After the Architect has issued a Certificate for Payment, the Owner shall make payment in the manner and
within the time provided in the Contract Documents, and shall so notify the Architect.
AIA Uocumont A201 "" — 2007. Copyright 0 1911, 1915, 1918. 1925, 1937, 1951, 19S8, 1961. 1963, 1966. 1970. 1976, 1987, 1997 and 2007 by The American
InlL fnslitute of Architects. All rights reserved. WARNING: This AIA11 Document is protected by U.S. Copyright Law and International Treaties, Unauthorized ��
reproduction or distribution of this AIA° ndcument, or any portion of it, may result In severe civil and criminal penaltles, and wllt be prosecuted to the
r maximum extent possible under the law. This document was produced by AIA software at 15;04;44 on 0g110I2014 under Ofd9r Na.29010e794%1 which expires
on 0912012014, and is not for resale.
User Notes: (1213612(547)
§ 9.6.2 The Contractor shal I pay each Subcontractor no later than seven days after receipt of payment from the Owner
the amount to which the Subcontractor is entitled, reflecting percentages actually retained from payments to the
Contractor on account of the Subcontractor's portion of the Work. The Contractor shall, by appropriate agreement
with each Subcontractor, require each Subcontractor to make payments to Sub -subcontractors in a similar manner,
§ 9.6.3'rhe Architect will, on request, furnish to a Subcontractor, if practicable, information regarding percentages of
completion or amounts applied for by the Contractor and action taken thereon by the Architect and Owner on account
of portions of the Work done by such Subcontractor,
§ 9.6.4 The Owner has the right to request written evidence from the Contractor that the Contractor has properly paid
Subcontractors and material and equipment suppliers amounts paid by the Owner to the Contractor for subcontracted
Work. If the Contractor fails to furnish such evidence within seven days, the Owner shall have the right to contact
Subcontractors to ascertain whether they have been properly paid, Neither the Owner nor Architect shall have an
obligation to pay or to see to the payment of money to a Subcontractor, except as may otherwise be required by law.
§ 9.6,5 Contractor payments to material and equipment suppliers shall be treated in a manner similar to that provided
in Sections 9,6,2, 9,63 and 9.6.4.
§ 9,6.6 A Certificate for Payment, a progress payment, or partial or entire use or occupancy of the Project by the
Owner shall not constitute acceptance of Work not in accordance with the Contract Documents.
§ 9,6.7 Unless the Contractor provides the Owner with a payment bond in the full penal sum of the Contract Sum,
payments received by the Contractor for Work properly performed by Subcontractors and suppliers shall be held by
the Contractor for those Subcontractors or suppliers who performed Work or furnished materials, or both, under
contract with the Contractor for which payment was made by the Owner. Nothing contained herein shall require
money to be placed in a separate account and not commingled with money of the Contractor, shall create any fiduciary
liability or tart liability on the part of the Contractor for breach of trust or shall entitle any person or entity to an award
of punitive damages against the Contractor for breach of the requirements of this provision.
§ 9.7 FAILURE OF PAYMENT
If the Architect does not issue a Certificate for Payment, through no fault of the Contractor, within seven days after
receipt of the Contractor's Application for Payment, or if the Owner does not pay the Contractor within seven days
after the date established in the Contract Documents the amount certified by the Architect or awarded by binding
dispute resolution, then the Contractor may, upon seven additional days' written notice to the Owner and Architect,
stop the Work until payment ofthe amount owing has been received. The Contract Time shall be extended
appropriately and the Contract Sum shall be increased by the amount of the Contractor's reasonable costs of
shut -down, delay and start-up, plus interest as provided for in the Contract Documents,
§ 9.8 SUBSTANTIAL COMPLETION
§ 9.8.1 Substantial Completion is the stage in the progress of the Work when the Work or designated portion thereof is
sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for
its intended use.
§ 9,8.2 When the Contractor considers that the Work, or a portion thereof which the Owner agrees to accept
separately, is substantially complete, the Contractor shall prepare and submit to the Architect a comprehensive list of
items to be completed or corrected prior to final payment. Failure to include an item on such list does not alter the
responsibility of the Contractor to complete all Work in accordance with the Contract Documents.
§ 9.8.3 Upon receipt of the Contractor's list, the Architect will make an inspection to determine whether the Work or
designated portion thereof is substantially complete. If the Architect's inspection discloses any item, whether or not
included on the Contractor's list, which is not sufficiently complete in accordance with the Contract Documents so
that the Owner can occupy or utilize the Work or designated portion thereof for its intended use, the Contractor shall,
before issuance of the Certificate of Substantial Completion, complete or correct such item upon notification by the
Architect. In such case, the Contractor shall then submit a request for another inspection by the Architect to determine
Substantial Completion.
AIA Document A201.M — 2007. Copyright Q 1911, 1915. 1916, 1925. 1937, 1951, 1968. 1961, 1953, 1955. 1970, 1975, 1987, 1997 and 2007 by The American
Init. Institute of Architects. All rights reservad, WARNING: This AIA- Document Is protested by U,S, Copyright Law and International Treaties. Unauthorized 25
reproduction or distribution of this AIA-1 Document, or any portion of It, may result In sovere civil and crlminal penalties, and will be prosecuted to the
1 maximum extent possible underthe taw. This documentwas produced hyAIA soflwereat 15:04:44 on 06110/2014 under Order No.2901087948_1 winch expires
an 0912012014, and Is not for resale.
User Notes: (1213612647)
§ 9.8.4 When the Work or designated portion thereof is substantially complete, the Architect will prepare a Certificate
of Substantial Completion that shall establish the date of Substantial Completion, shall establish responsibilities of the
Owner and Contractor for security, maintenance, heat, utilities, damage to the Work and insurance, and shall fix the
time within which the Contractor shall finish all items on the Iist accompanying the Certificate. Warranties required by
the Contract Documents shal I commence on the date of Substantial Completion of the Work or designated portion
thereof unless otherwise provided in the Certificate of Substantial Completion.
§ 9,8,5 The Certificate of Substantial Completion shall be submitted to the Owner and Contractor for their written
acceptance of responsibilities assigned to them in such Certificate. Upon such acceptance and consent of surety, ifany,
the Owner shall make payment of retainage applying to such Work or designated portion thereof. Such payment shall
be adjusted for Work that is incomplete or not in accordance with the requirements of the Contract Documents.
§ 9.9 PARTIAL OCCUPANCY OR USE
§ 9.9.1 "fhe Owner may occupy or use any completed or partially completed portion ofthe Work at any stage when
such portion is designated by separate agreement with the Contractor, provided such occupancy or use is consented to
by the insurer as required under Section 11.3.1.5 and authorized by public authorities having j urisdiction over the
Project. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided
the Owner and Contractor have accepted in writing the responsibilities assigned to each of them for payments,
retainage, if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing
concerning the period for correction of the Work and commencement of warranties required by the Contract
Documents. When the Contractor considers a portion substantially complete, the Contractor shall prepare and submit
a list to the Architect as provided under Section 9.8.2. Consent of the Contractor to partial occupancy or use shall not
be unreasonably withheld, The stage of the progress of the Work shall be determined by written agreement between
the Owner and Contractor or, i f no agreement is reached, by decision of the Architect.
§ 9.9.2 Immediately prior to such partial occupancy or use, the Owner, Contractor and Architect shall jointly inspect
the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work.
§ 9,9,3 Unless otherwise agreed upon, partial occupancy or use of portion or portions of the Work shall not constitute
acceptance of Work not complying with the requirements of the Contract Documents,
§ 910 FINAL COMPLETION AND FINAL PAYMENT
§ 9,10.1 Upon receipt of the Contractor's written notice that the Work is ready for final inspection and acceptance and
upon receipt of a final Application for Payment, the Architect will promptly make such inspection and, when the
Architect finds the Work acceptable under the Contract Documents and the Contract fully performed, the Architect
will promptly issue a Final Certificate for Payment stating that to the best of the Architect's knowledge, information
and belief, and on the basis of the Architect's on -site visits and inspections, the Work has been completed in
accordance with terms and conditions ofthe Contract Documents and that the entire balance found to be due the
Contractor and noted in the final Certificate is due and payable. The Architect's final Certificate for Payment will
constitute a further representation that conditions listed in Section 9.10.2 as precedent to the Contractor's being
entitled to final payment have been fulfilled.
§ 9.10,2 Neither final payment nor any remaining retained percentage shall become due until the Contractor submits to
the Architect (I) an affidavit that payrolls, bi Its far materials and equipment, and other indebtedness connected with
the Work for which the Owner or the Owner's property might be responsible or encumbered (less alrlounts withheld
by Owner) have been paid or otherwise satisfied, (2) a certificate evidencing that insurance required by the Contract
Documents to remain in force after final payment is currently in effect and will not be canceled or allowed to expire
until at least 36 days' prior written notice has been given to the Owner, (3) a written statement that the Contractor
knows of no substantial reason that the insurance will not be renewable to cover the period required by the Contract
Documents, (4) consent of surety, if any, to final payment and (5), if required by the Owner, other data establishing
payment or satisfaction of obligations, such as receipts, releases and waivers of liens, claims, security interests or
encumbrances arising out of the Contract, to the extent and in such form as may be designated by the Owner. If a
Subcontractor refuses to furnish a release or waiver required by the Owner, the Contractor may furnish a bond
satisfactory to the Owner to indemnify the Owner against such lien. If such lien remains unsatisfied after payments are
made, the Contractor shall refund to the Owner ail money that the Owner may be compelled to pay in discharging such
lien, including all costs and reasonable attorneys' fees.
Ink. AIA Document A247T" — 2001, 00pyrlghA Q 1911, 1915, 1sia, 1926, 1937, 1951, 1950. 1961, 1963, 1966, 1970. 1976. 1907, 1997 and 2007 by The American
Institute of Atphitecis, All nigh# re5ervad. WARNING: This AIAw Document is protected by U.S. Copyright Law and International Treaties. Unauthorized 25
reproduction or distribution of this AiAI Document, or any portion of It, may result in severe civil and criminal penalties, and will be prosecuted to the
j maximum extent possible under the law. This document was produced by MA sotiware at 15:04:44 on 0611012014 under Order No.2901097949_i which expires
on O912o12014, and Is not for resale,
User Notes: (1213612647)
§ 9.10.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault
of the Contractor or by issuance of Change Orders affecting final completion, and the Architect so confirms, the
Owner shall, upon application by the Contractor and certification by the Architect, and without terminating the
Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining
balance for Work not fully completed or corrected is less than retainage stipulated in the Contract Documents, and if
bonds have been furnished, the written consent of surety to payment of the balance due for that portion of the Work
fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such
payment, Such payment shall be made under terms and conditions governing final payment, except that it shall not
constitute a waiver of claims.
§ 9.10.4 The making of final payment shall constitute a waiver of Claims by the Owner except those arising from
.1 liens, Claims, security interests or encumbrances arising out of the Contract and unsettled;
,2 failure of the Work to comply with the requirements of the Contract Documents; or
3 terms of special warranties required by the Contract Documents.
§ 9.10.5 Acceptance of final payment by the Contractor, a Subcontractor or material supplier shall constitute a waiver
of claims by that payee except those previously made in writing and identified by that payee as unsettled at the time of
final Application for Payment.
ARTICLE 10 PROTECTION OF PERSONS AND PROPERTY
§ 10.1 SAFETY PRECAUTIONS AND PROGRAMS
The Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in
connection with the performance of the Contract.
§ 10.2 SAFETY OF PERSONS AND PROPERTY
§ 10.2.1 The Contractor shall take reasonable precautions for safety of, and shall provide reasonable protection to
prevent damage, injury or loss to
.1 employees on the Work and other persons who may be affected thereby;
1 the Work and materials and equipment to be incorporated therein, whether in storage on or off the site,
under care, custody or control of the Contractor or the Contractor's Subcontractors or
Sub -subcontractors; and
.3 other property at the site or adjacent thereto, such as trees, shrubs, lawns, walks, pavements, roadways,
structures and utilities not designated for removal, relocation or replacement in the course of
construction.
§ 10.22 The Contractor shall comply with and give notices required by applicable laws, statutes, ordinances, codes,
rules and regulations, and lawful orders of public authorities bearing on safety of persons or property or their
protection from damage, injury or loss.
§ 10.2.3 The Contractor shall erect and maintain, as required by existing conditions and performance of the Contract,
reasonable safeguards for safety and protection, including posting danger signs and other warnings against hazards,
promulgating safety regulations and notifying owners and users of adjacent sites and utilities.
§ 10.2.4 When use or storage of explosives or other hazardous materials or equipment or unusual methods are
necessary for execution of the Work, the Contractor shall exercise utmost care and carry on such activities under
supervision of properly qualified personnel,
§ 10.2.5 The Contractor shall promptly remedy damage and loss (other than damage or loss insured under property
insurance required by the Contract Documents) to property referred to in Sections 10.2.1.2 and 10.2.1.1 caused in
whole or in part by the Contractor, a Subcontractor, a Sub -subcontractor, or anyone directly or indirectly employed by
any of them, or by anyone for whose acts they may be liable and for which the Contractor is responsible under Sections
10.11.2 and 10.2. L3, except damage or loss attributable to acts or omissions of the Owner or Architect or anyone
directly or indirectly employed by either of them, or by anyone for whose acts either of them may be liable, and not
attributable to the fault or negligence of the Contractor. The foregoing obligations of the Contractor are in addition to
the Contractor's obligations tinder Section 3.19.
Init. Al Doaument A201 N — 2007• Copyright Q 1911. 1915. 1918, 1925. 1937, 1951, 1958, 1961, 1963, 1966, 1970, 1976, 1987. 1997 and Z007 by The American
institute of Architects. All rights reserved. WARNING: This AIA11 Document Is protected by U.S. Copyright Law and International Treaties. UnautltoNzed 7
reproduction or distribution of this AIA° Document, or any portion of it, may result in savrre clv II and Criminal pQn IN95, and will be prp"cuted to the
f maximum extent possible under the law. This docurnem was produced by AIA software at 16 04:b4 on 0611012014 under Order No-29010070481 which expires
on f19/2Df2Q14, and iS not for resale.
User Notes: 0213612947)
§ 1016 The Contractor shall designate a responsible member of the Contractor's organization at the site whose duty
shall be the prevention of accidents. This person shall be the Contractor's superintendent unless otherwise designated
by the Contractor in writing to the Owner and Architect.
§ 10.2.7 The Contractor shall not permit any part of the construction or site to be loaded so as to cause damage or
create an unsafe condition.
§ 10.2.8INJURY OR DAMAGE TO PERSON OR PROPERTY
If either party suffers injury or damage to person or property because of an actor omission of the other party, or of
others for whose acts such party is legally responsible, written notice of such injury or damage, whether or not insured,
shall be given to the other party within a reasonable time not exceeding 21 days after discovery. The notice shall
provide sufficient detail to enable the other party to investigate the matter,
§ 10.3 HAZARDOUS MATERIALS
§ 10.3.1 The Contractor is responsible for compliance with any requirements included in the Contract Documents
regarding hazardous materials. If the Contractor encounters a hazardous material or substance not addressed in the
Contract Documents and if reasonable precautions will be inadequate to prevent foreseeable bodily injury or death to
persons resulting from a material or substance, including but not limited to asbestos or polychlorinated biphenyl
(PCB), encountered on the site by the Contractor, the Contractor shall, upon recognizing the condition, immediately
stop Work in the affected area and report the condition to the Owner and Architect in writing.
§ 10.3,2 Upon receipt of the Contractor's written notice, the Owner shall obtain the services of licensed laboratory to
verify the presence or absence of the material or substance reported by the Contractor and, in the event such material or
substance is found to be present, to cause it to be rendered harmless. Unless otherwise required by the Contract
Documents, the Owner shall furnish in writing to the Contractor and Architect the names and qualifications of persons
or entities who are to perform tests verifying the presence or absence of such material or substance or who are to
perform the task of removal or safe containment of such material or substance. The Contractor and the Architect wi 11
promptly reply to the Owner in writing stating whether or not either has reasonable objection to the persons or entities
proposed by the Owner. If either the Contractor or Architect has an objection to a person or entity proposed by the
Owner, the Owner shall propose another to whom the Contractor and the Architect have no reasonable abjection.
When the material or substance has been rendered harmless, Work in the affected area shall resume upon written
agreement of the Owner and Contractor. By Change Order, the Contract Time shall be extended appropriately and the
Contract Sum shall be increased in the amount of the Contractor's reasonable additional costs of shut -down, delay and
start-up.
§ 10,3.3 To the fullest extent permitted by law, the Owner shall indemnify and hold harmless the Contractor,
Subcontractors, Architect, Architect's consultants and agents and employees of any of them from and against claims,
damages, losses and expenses, including but not limited to attorneys' fees, arising out of or resulting from
performance of the Work in the affected area if in fact the material or substance presents the risk of bodily injury or
death as described in Section 10,3.1 and has not been rendered harmless, provided that such claim, damage, loss or
expense is attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property
(other than the Work itself], except to the extent that such damage, loss or expense is due to the fault or negligence of
the party seeking indemnity,
§ 10.3,4 The Owner shall not be responsible under this Section 10.3 for materials or substances the Contractor brings
to the site unless such materials or substances are required by the Contract Documents. The Owner shall be responsible
for materials or substances required by the Contract Documents, except to the extent of the Contractor's fault or
negligence in the use and handling of such materials or substances.
§ 10.3,5 The Contractor shall indemnify the Owner for the cost and expense the Owner incurs (1) for remediation of a
material or substance the Contractor brings to the site and negligently handles, or (2) where the Contractor fails to
perform its obligations under Section 10.3.1, except to the extent that the cost and expense are due to the Owner's fault
or negligence.
§ 10,3,6 If; without negligence on the part of the Contractor, the Contractor is held liable by a government agency for
the cost of remediation of a hazardous material or substance solely by reason of performing Work as required by the
Contract Documents, the Owner shall indemnify the Contractor for all cost and expense thereby incurred.
AIA Document A201 va — 2007, Copyright Z 1911, 1916, 1918, 1925, 1937, 1951, 1958, 1961, 1063, 1966. 1970, 1976. 1987, 1997 and 2007 by The American
Init. Institute of Archilects. All rights reserved. WARNING: This AIAI Document is protected by U.S. Copyright Law and International Troaties. Unauthorized 28
reproduction or distribution or this AIA/0 Document, or any portion of It, may result In severe civil and criminal penalties, and will be prosecuted to the
maximum eKlent possible under the law. This document was produced by AIA software at 15 04 44 on 06?10/2014 under Order No.2901087948_1 which expires
on 0912012014, and is not for rar,ale.
User Notes: (1213612647)
§ 10.4 EMERGENCIES
In an emergency affecting safety of persons or property, the Contractor shall act, at the Contractor's discretion, to
prevent threatened damage, injury or loss. Additional compensation or extension of time claimed by the Contractor on
account of an emergency shall be determined as provided in Article 15 and Article 7.
ARTICLE 11 INSURANCE AND BONDS
§ 11.1 CONTRACTOR'S LIABILITY INSURANCE
§ 11.1.1 The Contractor shall purchase from and maintain in a company or companies lawfully authorized to do
business in the jurisdiction in which the Project is located such insurance as will protect the Contractor from claims set
forth below which may arise out of or result From the Contractor's operations and completed operations tinder the
Contract and for which the Contractor may be legally liable, whether such operations be by the Contractor or by a
Subcontractor or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them
may be liable:
.1 Claims under workers' compensation, disability benefit and other similar employee benefit acts that are
applicable to the Work to be performed;
.2 Claims for damages because of bodily injury, occupational sickness or disease, or death of the
Contractor's employees;
.3 Claims for damages because of bodily injury, sickness or disease, or death of any person other than the
Contractor's employees;
,4 Claims for damages insured by usual personal injury liability coverage;
.5 Claims for damages, other than to the Work itself, because of injury to or destruction of tangible
property, including loss of use resulting therefrom;
.6 Claims for damages because of bodily injury, death of a person or property damage arising out of
ownership, maintenance or use of motor vehicle;
.7 Claims for bodily injury or property damage arising out of completed operations; and
.S Claims involving contractual liability insurance applicable to the Contractor's obligations under
Section 3.18.
§ 11.1.2 The insurance required by Section 11,1.1 shall be written for not less than limits of liability specified in the
Contract Documents or required by Iaw, whichever coverage is greater. Coverages, whether written on an occurrence
or claims -made basis, shall be maintained without interruption from the date of commencement of the Work until the
date of final payment and termination of any coverage required to be maintained after final payment, and, with respect
to the Contractor's completed operations coverage, unti I the expiration of the period for correction of Work or for such
other period for maintenance of completed operations coverage as specified in the Contract Documents.
§ 11.1.3 Certi ficates of insurance acceptable to the Owner shall be tiled with the Owner prior to commencement of the
Work and thereafter upon renewal or replacement of each required policy of insurance. These certificates and the
insurance policies required by this Section 1 1,1 shall contain a provision that coverages afforded under the policies
will not be canceled or allowed to expire until at least 30 days' prior written notice has been given to the Owner. An
additional certificate evidencing continuation of liability coverage, including coverage for completed operations, shall
be submitted with the final Application For Payment as required by Section 9.10 2 and thereafter upon renewal or
replacement ofsuch coverage until the expiration of the time required by Section 1 1.1.2. Information concerning
reduction of coverage on account of revised limits or claims paid under the General Aggregate, or both, shall be
furnished by the Contractor with reasonable promptness.
§ 11.1,4 The Contractor shall cause the commercial liability coverage required by the Contract Documents to include
(1) the Owner, the Architect and the Architect's consultants as additional insureds for claims caused in whole or in part
by the Contractor's negligent acts or omissions during the Contractor's operations; and (2) the Owner as an additional
insured for claims caused in whole or in part by the Contractor's negl igent acts or omissions during the Contractor's
completed operations.
§ 11,20WNER!S LIABILITY INSURANCE
The Owner shall be responsible for purchasing and maintaining the Owner's usual liability insurance.
Init AIA D*Cumgnt A2011M — 20t17'. Copyright * 1%11, 1916, 1918, 1925. 1937, 19b1, 1959, 1961, 1963, 1966, 1970. 1976. 1967. 1997 and 2007 by The American
InsI Rut$ of Ate4iteCtS. All rights reserved. WARNING: This AIAa Document Is protected by U.S. Copyright Law and International Troaties, Unauthorized
reproduction or distribution of this AIA° Document, or any portion of It. may result In severe civil and Criminal penalties, and will be pro5vCuted to the 29
f maximum extent possible under the law. This document was produced by AIA software at 15:D4:44 on 060ar2014 under Order No.2901 D57948_1 which Bxpire5
an 0912412014. and iS not for resale.
User Notes: (1213612647)
§ 11.3 PROPERTY INSURANCE
§ 11,3.1 Unless otherwise provided, the Owner shall purchase and maintain, in a company or companies lawfully
authorized to do business in the jurisdiction in which the Project is located, property insurance written on a builder's
risk "all-risk" or equivalent policy form in the amount of the initial Contract Sum, plus value of subsequent Contract
Modifications and cost of materials supplied or installed by others, comprising total value for the entire Project at the
site on a replacement cost basis without optional deductibles. Such property insurance shall be maintained, unless
otherwise provided in the Contract Documents or otherwise agreed in writing by all persons and entities who are
beneficiaries of such insurance, until final payment has been made as provided in Section 9.10 or until no person or
entity other than the Owner has an insurable interest in the property required by this Section 113 to be covered,
whichever is later. This insurance shall include interests of the Owner, the Contractor, Subcontractors and
Sub -subcontractors in the Project.
§ 11.3.1.1 Property insurance shall be on an "all-risk" or equivalent policy form and shall include, without limitation,
insurance against the perils of fire (with extended coverage) and physical loss or damage including, without
duplication of coverage, theft, vandalism, malicious mischief, collapse, earthquake. flood, windstorm, falwwork,
testing and startup, temporary buildings and debris removal including demolition occasioned by enforcement of any
applicable legal requirements, and shall cover reasonable compensation for Architect's and Contractor's services and
expenses required as a result of such insured loss.
§ 11.3.1.2 If the Owner does not intend to purchase such property insurance required by the Contract and with all of the
coverages in the amount described above, the Owner shall so inform the Contractor in writing prior to commencement
of the Work. The Contractor may then effect insurance that will protect the interests ofthe Contractor, Subcontractors
and Sub -subcontractors in the Work, and by appropriate Change Order the cost thereof shall be charged to the Owner.
If the Contractor is damaged by the failure or neglect of the Owner to purchase or maintain insurance as described
above, without so notifying the Contractor in writing, then the Owner shall bear al I reasonable costs properly
attributable thereto,
§ 11.3.1.3 If the property insurance requires deductibles, the Owner shall pay costs not covered because of such
deductibles,
§ 11.3.1.4 This property insurance shall cover portions of the Work stored off the site, and also portions of the Work in
transit,
§ 11.3.1.5 Partial occupancy or use in accordance with Section 9.9 shal I not commence until the insurance company or
companies providing property insurance have consented to such partial occupancy or use by endorsement or
otherwise. The Owner and the Contractor shall take reasonable steps to obtain consent of the insurance company or
companies and shall, without mutual written consent, take no action with respect to partial occupancy or use that
would cause cancellation, lapse or reduction of insurance,
§ 11.3.2901LER AND MACHINERY INSURANCE
The Owner shall purchase and maintain boiler and machinery insurance required by the Contract Documents or by
law, which shall specifically cover such insured objects during installation and until final acceptance by the Owner;
this insurance shall include interests of the Owner, Contractor, Subcontractors and Sub -subcontractors in the Work,
and the Owner and Contractor shall be named insureds.
§ 11.3.3 LOSS OF USE INSURANCE
The Owner, at the Owner's option, may purchase and maintain such insurance as will insure the Owner against loss of
use of the Owner's property due to fire or other hazards, however caused. The Owner waives all rights of action
against the Contractor for loss of use of the Owner's property, including consequential losses due to fire or other
hazards however caused.
§ 11.3.4 If the Contractor requests in writing that insurance for risks other than those described herein or other special
causes of loss be included in the property insurance policy, the Owner shall, if possible, include such insurance, and
the cost thereof shall be charged to the Contractor by appropriate Change Order,
§ 11.3,5 if during the Project construction period the Owner insures properties, real or personal or both, at or adjacent
to the site by property insurance under policies separate from those insuring the Project, or if after final payment
Init AIA Document A201 +M — 2007. Copyright C 1911. 1915, 191 a. 1925, 1937. 1951, 1958, 1961, 1963. 1966, 1970, 1976. 1987, 1997 and 2007 by The American
Institute of Archilects, All rights reserved. WARNING: This AIWI Document Is protested by U.S. Copyright Law and International Treaties. Unauthorized
reproduction or distribution of this AIAc Document, or any portion of It, may result In sevore civil and criminal penalties, and will be prp!5ecute4 to the
! maximum extant possible under the law. This document was produced by AIA software at 15,04-44 on 06/10/2014 under Order No.2901087048_1 which expires
on 0912012014, and Is not for resale.
User Autos: ( 1213612647)
property insurance is to be provided on the completed Project through a policy or policies other than those insuring the
Project during the construction period, the Owner shall waive all rights in accordance with the terms of Section 11.3.7
for damages caused by fire or other causes of loss covered by this separate property insurance. All separate policies
shall provide this waiver of subrogation by endorsement or otherwise,
§ 11.3.6 Before an exposure to loss may occur, the Owner shall file with the Contractor a copy of each policy that
includes insurance coverages required by this Section 113. Each policy shall contain all generally applicable
conditions, definitions, exclusions and endorsements related to this Project. Each policy shall contain a provision that
the policy will not be canceled or allowed to expire, and that its limits will not be reduced, until at least 30 days' prior
written notice has been given to the Contractor.
§ 11.3.7 WAIVERS OF SUBROGATION
The Owner and Contractor waive all rights against (1) each other and any of their subcontractors, sub -subcontractors,
agents and employees, each of the other, and (2) the Architect, Architect's consultants, separate contractors described
in Article 6, if any, and any of their subcontractors, sub -subcontractors, agents and employees, for damages caused by
fire or other causes of loss to the extent covered by property insurance obtained pursuant to this Section 11.3 or other
property insurance applicable to the Work, except such rights as they have to proceeds of such insurance held by the
Owner as fiduciary. The Owner or Contractor, as appropriate, shall require of the Architect, Architect's consultants,
separate contractors described in Article 6, if any, and the subcontractors, sub -subcontractors, agents and employees
of any of them, by appropriate agreements, written where legally required for validity, similar waivers each in favor of
other parties enumerated herein, The policies shall provide such waivers of subrogation by endorsement or otherwise.
A waiver of subrogation shall be effective as to a person or entity even though that person or entity would otherwise
have a duty of indemnification, contractual or otherwise, did not pay the insurance premium directly or indirectly, and
whether or not the person or entity had an insurable interest in the property damaged.
§ 11.3.8 A loss insured under the Owner's property insurance shall be adjusted by the Owner as fiduciary and made
payable to the Owner as Fiduciary for the insureds, as their interests may appear, subject to requirements of any
applicable mortgagee clause and of Section 1 1.3.10. The Contractor shall pay Subcontractors their just shares of
insurance proceeds received by the Contractor, and by appropriate agreements, written where legally required for
validity, shall require Subcontractors to make payments to their Sub -subcontractors in similar manner.
§ 11.3.9 If required in writing by a party in interest, the Owner as fiduciary shall, upon occurrence of an insured loss,
give bond for proper performance of the Owner's duties. The cost of required bonds shall be charged against proceeds
received as fiduciary. The Owner shall deposit in a separate account proceeds so received, which the Owner shall
distribute in accordance with such agreement as the parties in interest may reach, or as determined in accordance with
the method of binding dispute resolution selected in the Agreement between the Owner and Contractor. If after such
loss no other special agreement is made and unless the Owner terminates the Contract for convenience, replacement of
damaged property shall be performed by the Contractor after notification of a Change in the Work in accordance with
Article 7.
§ 11.3.1D The Owner as fiduciary shall have power to adjust and settle a loss with insurers unless one of the parties in
interest shall object in writing within five days after occurrence of loss to the Owner's exercise of this power; if such
objection is made, the dispute shall be resolved in the manner selected by the Owner and Contractor as the method of
binding dispute resolution in the Agreement. if the Owner and Contractor have selected arbitration as the method of
binding dispute resolution, the Owner as fiduciary shall make settlement with insurers or, in the case of a dispute over
distribution of insurance proceeds, in accordance with the directions of the arbitrators.
§ 11.4 PERFORMANCE BOND AND PAYMENT BOND
§ 11.4.1 The Owner shall have the right to require the Contractor to furnish bonds covering faithful performance of the
Contract and payment of obligations arising thereunder as stipulated in bidding requirements or specifically required
in the Contract Documents on the date of execution of the Contract.
g 11.4,2 Upon the request of any person or entity appearing to be a potential beneficiary of bonds covering payment of
obligations arising under the Contract, the Contractor shall promptly furnish a copy of the bonds or shall authorize a
copy to be furnished.
loll Institute
Documerd A201 - — 2007. Copyright C 1911, 1915, 1918, 1925, 1937, 1951, 1958, 1981, 1983, 1g%. 1970, 1975, 1907, 1997 and 2007 by The American
Institute of Architects. An rights reserved. WARNING: This AIA, Document is protected by U.S. Copyright Law and International Treaties, Unauthorized 31
reproduction ordlatrlbutlon afthie AIA° Document, or any portion of It, may result in savers civil and criminal penalties, and will 139 prgsecuted tnthe
maximum extent possible under the law, This document was produced by AIA software at 15:04:44 on 0611012014 under Order No.2901087949_1 which expires
on 0912012014, and is not for resale.
User Notes: (1213612647)
ARTICLE 12 UNCOVERING AND CORRECTION OF WORK
§ 12.1 UNCOVERING OF WORK
§ 12.1.1 If a portion ofthe Work is covered contrary to the Architect's request or to requirements specifically
expressed in the Contract Documents, it must, if requested in writing by the Architect, be uncovered for the Architect's
examination and be replaced at the Contractor's expense without change in the Contract Time.
§ 12.1.2 Ifa portion of the Work has been covered that the Architect has not specifically requested to examine prior to
its being covered, the Architect may request to see such Work and it shall be uncovered by the Contractor. If such
Work is in accordance with the Contract Documents, costs of uncovering and replacement shall, by appropriate
Change Order, be at the Owner's expense. If such Work is not in accordance with the Contract Documents, such costs
and the cost of correction shall be at the Contractor's expense unless the condition was caused by the Owner or a
separate contractor in which event the Owner shall be responsible for payment of such costs.
§ 12.2 CORRECTION OF WORK
§ 12.2.1 BEFORE OR AFTER SUBSTANTIAL COMPLETION
The Contractor shall promptly correct Work rejected by the Architect or fail ing to conform to the requirements of the
Contract Documents, whether discovered before or after Substantial Completion and whether or not fabricated,
installed or completed. Costs ofcorrectingsuch rejected Work, including additional testing and inspections, the cost of
uncovering and replacement, and compensation For the Architect's services and expenses made necessary thereby,
shall be at the Contractor's expense.
§ 12.2.2 AFTER SUBSTANTIAL COMPLETION
§ 12.2.2.1 In addition to the Contractor's obligations under Section 3.5, if, within one year after the date of Substantial
Completion of the Work or designated portion thereof or after the date For commencement of warranties established
under Section 9.9.1, or by terms of an applicable special warranty required by the Contract Documents, any of the
Work is Found to be not in accordance with the requirements of the Contract Documents, the Contractor shall correct it
promptly after receipt of written notice from the Owner to do so unless the Owner has previously given the Contractor
a written acceptance of such condition. The Owner shall give such notice promptly after discovery of the condition.
During the one-year period for correction of Work, if the Owner fails to notify the Contractor and give the Contractor
an opportunity to make the correction, the Owner waives the rights to require correction by the Contractor and to make
a claim for breach of warranty. If the Contractor Fails to correct nonconforming Work within a reasonable time during
that period after receipt of notice from the Owner or Architect, the Owner may correct it in accordance with Section
2.4.
§ 12.2.2.2 The one-year period for correction of Work shall be extended with respect to portions of Work first
performed after Substantial Completion by the period of time between Substantial Completion and the actual
completion of that portion of the Work.
§ 12,223 The one-year period for correction of Work shall not be extended by corrective Work performed by the
Contractor pursuant to this Section 12.2.
§ 12.2.3 The Contractor shall remove from the site portions ofthe Work that are not in accordance with the
requirements of the Contract Documents and are neither corrected by the Contractor nor accepted by the Owner.
§ 12.2.4 The Contractor shall bear the cost of correcting destroyed or damaged construction, whether completed or
partially completed, of the Owner or separate contractors caused by the Contractor's correction or removal of Work
that is not in accordance with the requirements of the Contract Documents,
§ 12.2.5 Nothing contained in this Section 12.2 shall be construed to establish a period of limitation with respect to
other obligations the Contractor has under the Contract Documents, Establishment of the one-year period for
correction of Work as described in Section 12.2.2 relates only to the specific obligation ofthe Contractor to correct the
Work, and has no relationship to the time within which the obligation to comply with the Contract Documents may be
sought to be enforced, nor to the time within which proceedings may be commenced to establish the Contractor's
liability with respect to the Contractor's obligations other than specifically to correct the Work.
AIA Document A201` - 2007. Copyright 0 1911, 1915, 1910. 1925, 1937. 1951, 1958. 1961. 1963, 1966. 1970, 1978. 1987, 1997 and 2007 by The American
Init. Inalitule of Architects. All rights reserved. WARNING: This AIAs' Document Is protected by U.S. copyright Law and International Treaties. Unauthorized
reproduction or distribution of this AIA°i ❑ocument, or any portion of It, may result In severe civil and criminal penattlos, and wilt be prosecuted to the
maximum extant possible undar the law. Thus document was produced uy AIA software sl 15:04;44 on 0611012014 under Order No.2801087846_1 which expires
on 0912012014, end is not for resale.
User Notas: (1213612647)
§ 12.3 ACCEPTANCE OF NONCONFORMING WORK
If the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the
Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as
appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.
ARTICLE 13 MISCELLANEOUS PROVISIONS
§ 13.1 GOVERNING LAIN
The Contract shall be governed by the law of the place where the Project is located except that, if the parties have
selected arbitration as the method of binding dispute resolution, the Federal Arbitration Act shall govern Section 15.4.
§ 13.2 SUCCESSORS AND ASSIGNS
§ 13.2.1 The Owner and Contractor respectively bind themselves, their partners, successors, assigns and legal
representatives to covenants, agreements and obligations contained in the Contract Documents. Except as provided in
Section 13.2.2, neither party to the Contract shall assign the Contract as a whole without written consent of the other,
If either party attempts to make such an assignment without such consent, that party shall nevertheless remain legally
responsible for all obligations under the Contract.
§ 13.2.2 The Owner may, without consent of the Contractor, assign the Contract to a lender providing construction
financing for the Project, if the lender assumes the Owner's rights and obligations under the Contract Documents. 'rhe
Contractor shall execute all consents reasonably required to facilitate such assignment.
§ 13.3 WRITTEN NOTICE
Written notice shall be deemed to have been duly served if delivered in person to the individual, to a member of the
firm or entity, or to an officer of the corporation for which it was intended; or if delivered at, or sent by registered or
certified mail or by courier service providing proof of delivery to, the last business address known to the party giving
notice.
§ 13.4 RIGHTS AND REMEDIES
§ 13.4.1 Duties and obligations imposed by the Contract Documents and rights and remedies available thereunder
shall be in addition to and not a limitation of duties, obligations, rights and remedies otherwise imposed or available by
law.
§ 13.4.2 No action or failure to act by the Owner, Architect or Contractor shall constitute a waiver of a right or duty
afforded them under the Contract, nor shall such action or failure to act constitute approval of or acquiescence in a
breach there under, except as may be specifically agreed in writing.
§ 13.5 TESTS AND INSPECTIONS
§ 13,5.1 Tests, inspections and approvals of portions of the Work shall be made as required by the Contract
Documents and by applicable laws, statutes, ordinances, codes, rules and regulations or lawful orders of public
authorities. Unless otherwise provided, the Contractor shall make arrangements for such tests, inspections and
approvals with an independent testing laboratory or entity acceptable to the Owner, or with the appropriate public
authority, and shall bear all related costs of tests, inspections and approvals. The Contractor shall give the Architect
timely notice of when and where tests and inspections are to be made so that the Architect may be present for such
procedures. The Owner shall bear costs of (1) tests, inspections or approvals that do not become requirements until
after bids are received or negotiations concluded, and (2) tests, inspections or approvals where building codes or
applicable laws or regulations prohibit the Owner from delegating their cost to the Contractor.
§ 13.5.2 If the Architect. Owner or public authorities having jurisdiction determine that portions of the Work require
additional testing, inspection or approval not included under Section 13.5.1, the Architect will, upon written
authorization from the Owner, instruct the Contractor to make arrangements for such additional testing, inspection or
approval by an entity acceptable to the Owner, and the Contractor shall give timely notice to the Architect of when and
where tests and inspections are to be made so that the Architect may be present for such procedures. Such costs, except
as provided in Section 13.5.3, shall be at the Owner's expense.
§ 13.5.3 If such procedures for testing, inspection or approval under Sections 13.5.1 and 13.5.2 reveal failure of the
portions of the Work to comply with requirements established by the Contract Documents, all costs made necessary by
AIA t74Cr1e16r1t A201 rM — 2007. Copyright $1911, 1915, 1918, 1925. 1937, 1951, 1958. 1961, 1963. 1966, 1970, 1976. 1987, 1997 and 2007 by Tha American
tnit institute of Architects. All rights reserved. WARNING: This AIA1 Document is protected by U.9. Copyright Law and International Treaties_ Unauthorized
reproduction or distribution of this AEA°i Dooument, or any portion of It, may result in severe civil and criminal penalties, and will be prom ocuted to tho 33
r maximum extant possible under the law. This documant was produced by AIA software at 15:04:44 on W1012014 under Order No,2B01087948_1 which expires
on 0912012014, and is not far resale.
User Notes: (1213612647)
such failure including those of repeated procedures and compensation for the Architect's services and expenses shall
be at the Contractor's expense.
§ 13.5.4 Required certificates of testing, inspection or approval shall, unless otherwise required by the Contract
Documents, be secured by the Contractor and promptly delivered to the Architect.
§ 13.5.5 If the Architect is to observe tests, inspections or approvals required by the Contract Documents, the Architect
will do so promptly and, where practicable, at the normal place of testing.
§ 13.5.6 Tests or inspections conducted pursuant to the Contract Documents shall be made promptly to avoid
unreasonable delay in the Work.
§ 13.6INTEREST
Payments due and unpaid under the Contract Documents shall bear interest from the date payment is due at such rate
as the parties may agree upon in writing or, in the absence thereof, at the legal rate prevailing from time to time at the
place where the Project is located.
§ 13.7 TIME LIMITS ON CLAIMS
The Owner and Contractor shall commence all claims and causes of action, whether in contract, tort, breach of
warranty or otherwise, against the other arising out ofor related to the Contract in accordance with the requirements of
the final dispute resolution method selected in the Agreement within the time period specified by applicable law, but in
any case not more than 10 years after the date of Substantial Completion of the Work. The Owner and Contractor
waive all claims and causes of action not commenced in accordance with this Section 13.7.
ARTICLE 14 TERMINATION OR SUSPENSION OF THE CONTRACT
§ 14,1 TERMINATION BY THE CONTRACTOR
§ 14,1.1 "rhe Contractor may terminate the Contract if the Work is stopped for a period of 30 consecutive days through
no act or fault of the Contractor or a Subcontractor, Sub -subcontractor or their agents or employees or any other
persons or entities performing portions of the Work under direct or indirect contract with the Contractor, for any of the
following reasons'
.1 Issuance of an order of court or other public authority having jurisdiction that requires all Work to be
stopped;
.2 An act ofgovernnient, such as a declaration ofnational emergency that requires at I Work to be stopped;
.3 Because the Architect has not issued a Ccrtifcate for Payment and has not not1 hed the Contractor ofthe
reason for withholding certification as provided in Section 9,4.1, or because the Owner has not made
payment on a Certificate for Payment within the time stated in the Contract Documents; or
.4 The Owner has failed to furnish to the Contractor promptly, upon the Contractor's request, reasonable
evidence as required by Section 2.2.1.
§ 14.1.2 The Contractor may terminate the Contract if, through no act or fault of the Contractor or a Subcontractor,
Sub -subcontractor or their agents or employees or any other persons or entities performing portions of the Work under
direct or indirect contract with the Contractor, repeated suspensions, delays or interruptions of the entire Work by the
Owner as described in Section 143 constitute in the aggregate more than 100 percent of the total number of days
scheduled for completion, or 120 days in any 365-day period, whichever is less.
§ 14.1.3 If one of the reasons described in Section 14.1.1 or 14.1.2 exists, the Contractor may, upon seven days'
written notice to the Owner and Architect, terminate the Contract and recover from the Owner payment for Work
executed, including reasonable overhead and profit, costs incurred by reason of such termination, and damages.
§ 14.1.4 If the Work is stopped for a period of 60 consecutive days through no act or fault of the Contractor or a
Subcontractor or their agents or employees or any other persons performing portions of the Work under contract with
the Contractor because the Owner has repeatedly failed to fulfill the Owner's obligations under the Contract
Documents with respect to matters important to the progress of the Work, the Contractor may, upon seven additional
days' written notice to the Owner and the Architect, terminate the Contract and recover from the Owner as provided in
Section 14.I.3.
Init. AIA Document A201'a — 2047. Copyright Q 1911, 1915. 1918. 1925. 1937, 1961, 1988. 1961, 1963. 1966, 1970, 1976, 1987. 1997 and 2007 by The American
Institute of Architects, All rights reserved. WARNING: This AIAw Document is protected by U.S. copyright Law and International Treaties. Unauthorixod 34
reproduction or distribution of this AIM Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosacutatl to the
f maximum extant possible underthe law. This document was produced by AIA softwareat 15:04,44 on OWIG12014 under Order No.290106794fd_1 which expires
on 0912012414, and is not for resale.
User Notes: (1213612647)
§ 14.2 TERMINATION BY THE OWNER FOR CAUSE
§ 14.2.1 The Owner may terminate the Contract if the Contractor
.1 repeatedly refuses or fails to supply enough properly skilled workers or proper materials;
.2 fails to make payment to Subcontractors for materials or labor in accordance with the respective
agreements between the Contractor and the Subcontractors;
.3 repeatedly disregards applicable laws, statutes, ordinances, codes, rules and regulations, or lawful
orders of public authority; or
.4 otherwise is guilty of substantial breach of a provision of the Contract Documents.
§ 14.2.2 When any of the above reasons exist, the Owner, upon certification by the Initial decision Maker that
sufficient cause exists to justify such action, may without prejudice to any other rights or remedies of the Owner and
after giving the Contractor and the Contractor's surety, if any, seven days' written notice, terminate employment of the
Contractor and may, subject to any prior rights of the surety:
.1 Exclude the Contractor from the site and take possession of all materials, equipment, tools, and
construction equipment and machinery thereon owned by the Contractor;
.2 Accept assignment of subcontracts pursuant to Section 5.4; and
.3 Finish the Work by whatever reasonable method the Owner may deem expedient. Upon written request
of the Contractor, the Owner shall furnish to the Contractor a detailed accounting of the costs incurred
by the Owner in finishing the Work,
§ 14,2.3 When the Owner terminates the Contract for one of the reasons stated in Section 14.2.1, the Contractor shall
not be entitled to receive further payment until the Work is finished.
§ 14.2.4 If the unpaid balance ❑fthe Contract Sum exceeds costs of finishing the Work, including compensation for
the Architect's services and expenses made necessary thereby, and other damages incurred by the Owner and not
expressly waived, such excess shall be paid to the Contractor. If such costs and damages exceed the unpaid balance,
the Contractor shall pay the difference to the Owner. The amount to be paid to the Contractor or Owner, as the case
may be, shall be certified by the Initial Decision Maker, upon application, and this obligation for payment shall survive
termination of the Contract.
§ 14.3 SUSPENSION BY THE OWNER FOR CONVENIENCE
§ 14.3,1 The Owner may, without cause, order the Contractor in writing to suspend, delay or interrupt the Work in
whole or in part for such period of time as the Owner may determine.
§ 1412 The Contract Sum and Contract'rime ime shall be adjusted for increases in the cost and time caused by
suspension, delay or interruption as described in Section 14.3.1. Adjustment of the Contract Sum shall include profit.
No adjustment shall be made to the extent
.1 that performance is, was or would have been so suspended, delayed or interrupted by another cause for
which the Contractor is responsible; or
.2 that an equitable adjustment is made or denied under another provision of the Contract.
§ 14.4 TERMINATION BY THE OWNER FOR CONVENIENCE
§ 14,4.1 The Owner may, at any time, terminate the Contract for the Owner's convenience and without cause.
§ 14.4.2 Upon receipt of written notice from the Owner of such termination for the Owner's convenience, the
Contractor shall
A cease operations as directed by the Owner in the notice;
.2 take actions necessary, or that the Owner may direct, for the protection and preservation of the Work;
and
.3 except for Work directed to be performed prior to the effective date of termination stated in the notice,
terminate all existing subcontracts and purchase orders and enter into no further subcontracts and
purchase orders.
§ 14.4.3 In case of such termination for the Owner's convenience, the Contractor shall be entitled to receive payment
for Work executed, and costs incurred by reason of such termination, along with reasonable overhead and profit on the
Work not executed,
AIA Document A201 T" — 2007. Copyright 01911, 1915, 1918. 1925. 1937, 1951, 1958. 1961, 1953, 1966, 1970, 1976, 1987, 1997 and 2007 by The American
Init. Institute of Architects. All rights reserved. WARNING: This AIIAll Document is protected by U.S. Copyright Law and International Treaties. unauthorized
raprOduotlan or distribution of this AIA°' Document, or any portion of It. may rosult in severe civil and criminal penalties, and win he prosecuted to the
maximum axtont poSsible under the law. This document was produced by AIA software a1 15:0444 on 0611012014 under Order No 2901087948_1 which expires
an 09120i2014, and is not for ramde.
User Not"; (1213612647)
ARTICLE 15 CLAIMS AND DISPUTES
§ 15.1 CLAIMS
§ 15.1.1 DEFINITION
A Claim is a demand or assertion by one of the parties seeking, as a matter of right, payment of money, or other relief
with respect to the terms of the Contract. The term "Claim" also includes other disputes and matters in question
between the Owner and Contractor arising out of or relating to the Contract. The responsibility to substantiate Claims
shall rest with the party making the Claim.
§ 15.1.2 NOTICE OF CLAIMS
Claims by either the Owner or Contractor must be initiated by written notice to the other party and to the Initial
Decision Maker with a copy sent to the Architect, if the Architect is not serving as the Initial Decision Maker. Claims
by either party must be initiated within 21 days after occurrence of the event giving rise to such Claim or within 21
days after the claimant first recognizes the condition giving rise to the Claim, whichever is later,
§ 15.1.3 CONTINUING CONTRACT PERFORMANCE
Pending final resolution of a Claim, except as otherwise agreed in writing or as provided in Section 9.7 and Article 14,
the Contractor shall proceed diligently with performance of the Contract and the Owner shall continue to make
payments in accordance with the Contract Documents. The Architect will prepare Change Orders and issue
Certificates for Payment in accordance with the decisions of the Initial Decision Maker.
§ 15.1ACLAIMS FOR ADDITIONAL COST
If the Contractor wishes to make a Claim for an increase in the Contract Sum, written notice as provided herein shall
be given before proceeding to execute the Work. Prior notice is not required for Claims relating to an emergency
endangering life or property arising under Section 10A,
§ 15.1.5 CLAIMS FOR ADDITIONAL TIME
§ 15.1.5.1 If the Contractor wishes to make a Claim for an increase in the Contract Time, written notice as provided
herein shall be given. The Contractor's Claim shall include an estimate of cost and of probable effect of delay on
progress of the Work. In the case of a continuing delay, only one Claim is necessary.
§ 15.1.52 If adverse weather conditions are the basis for a Claim for additional time, such Claim shall be documented
by data substantiating that weather conditions were abnormal for the period of time, could not have been reasonably
anticipated and had an adverse effect on the scheduled construction.
§ 15.1.6 CLAIMS FOR CONSEQUENTIAL DAMAGES
The Contractor and Owner waive Claims against each other for consequential damages arising out of or relating to this
Contract. This mutual waiver includes
.1 damages incurred by the Owner for rental expenses, For losses of use, income, profit, financing,
business and reputation, and for loss of management or employee productivity or ofthe services of such
persons; and
.2 damages incurred by the Contractor for principal office expenses including the compensation of
personnel stationed there, for losses of financing, business and reputation, and for loss of profit except
anticipated profit arising directly from the Work.
This mutual waiver is applicable, without limitation, to all consequential damages due to either party's termination in
accordance with Article 14. Nothing contained in this Section 15,1.6 shall be deemed to preclude an award of
liquidated damages, when applicable, in accordance with the requirements of the Contract Documents.
§ 15.2INITIAL DECISION
§ 15.2.1 Claims, excluding those arising under Sections 10.3, 10.4, 11.3.9, and 11.3.10, shall be referred to the Initial
Decision Maker for initial decision, The Architect will serve as the Initial Decision Maker, unless otherwise indicated
in the Agreement. Except For those Claims excluded by this Section 15.2,1, an initial decision shall be required as a
condition precedent to mediation of any Claim arising prior to the date final payment is due, unless 30 days have
passed after the Claim has been referred to the Initial Decision Maker with no decision having been rendered. Unless
the Initial Decision Maker and al] affected parties agree, the Initial Decision Maker will not decide disputes between
the Contractor and persons or entities other than the Owner.
Init AIA DacumentA201111 — 2007. Copyrighi C 1911, 1g15, 191t1, 7925, 19S7, 1451, 1$50. 1961, 1963, 1966, 1970, 1976, 1987. 1997 and 2007 by The American
Institute of Architects. All rights reServed, WARNING,; This AIA ° Pocurnent Is protested by U.S. Copyright Law and Intematlanal Treaties. Unauthorized
reproduction or distribution of this AIA41 Document, or any portion of It, may result In severe civil and criminal periattles, and will be prosecuted to the
r maximum extent possible under the law. This document was produced by AIA software at ISiO4:44 on 06/7012014 under Order No.2901097948_1 which expires
on 09120/2014, and is not for resale.
User Notm., (1213812647)
§ 1512 The Initial Decision Maker will review Claims and within ten days of the receipt of Claim take one or more
of the following actions: (1) request additional supporting data from the claimant or a response with supporting data
from the other party, (2) reject the Claim in whole or in part, (3) approve the Claim, (4) suggest a compromise, or (5)
advise the parties that the Initial Decision Maker is unable to resolve the Claim if the Initial Decision Maker lacks
sufficient information to evaluate the merits of the Claim or if the Initial Decision Maker concludes that, in the Initial
Decision Maker's sole discretion, it would be inappropriate for the Initial Decision Maker to resolve the Claim.
§ 15.2.3 In evaluating; Claims, the Initial Decision Maker may, but shall not be obligated to, consult with or seek
information from either party or from persons with special knowledge or expertise who may assist the Initial Decision
Maker in rendering a decision. The Initial Decision Maker may request the Owner to authorize retention of such
persons at the Owner's expense.
§ 16.2.4 If the Initial Decision Maker requests a party to provide a response to a Claim or to furnish additional
supporting data, such party shall respond, within ten days after receipt of such request, and shall either (1) provide a
response on the requested supporting data, (2) advise the Initial Decision Maker when the response or supporting data
will be furnished or (3) advise the Initial Decision Maker that no supporting data will be furnished. Upon receipt of the
response or supporting data, if any, the Initial Decision Maker will either reject or approve the Claim in whole or in
part.
§ 15.2.5 The Initial Decision Maker will render an initial decision approving or rejecting the Claim, or indicating that
the Initial Decision Maker is unable to resolve the Claim. This initial decision shall (I ) be in writing; (2) state the
reasons therefor; and (3) notify the parties and the Architect, if the Architect is not serving as the Initial Decision
Maker, of any change in the Contract Sum or Contract Time or both. The initial decision shall be final and binding on
the parties but subject to mediation and, if the parties fail to resolve their dispute through mediation, to binding dispute
resolution.
§ 15.2.6 Either party may file for mediation of an initial decision at any time, subject to the terms of Section 15.2.6.1
§ 15,2,6.1 Either party may, within 34 days from the date of an initial decision, demand in writing that the other party
File for mediation within 60 days of the initial decision, If such a demand is made and the party receiving the demand
fails to file for mediation within the time required, then both parties waive their rights to mediate or pursue binding
dispute resolution proceedings with respect to the initial decision.
§ 16.2.7 In the event of a Claim against the Contractor, the Owner may, but is not obligated to, notify the surety, if any,
of the nature and amount of the Claim. If the Claim relates to a possibility of a Contractor's default, the Owner may,
but is not obligated to, notify the surety and request the surety's assistance in resolving the controversy.
§ 15.2.8 If Claim relates to or is the subject ofa mechanic's lien, the party asserting such Claim may proceed in
accordance with applicable law to comply with the lien notice or riling deadlines.
§ 15.3 MEDIATION
§ 15.3.1 Claims, disputes, or other matters in controversy arising out of or related to the Contract except those waived
as provided for in Sections 9.10.4, 9.10.5, and 15.1.6 shall be subject to mediation as a condition precedent to binding
dispute resolution.
§ 15.3.2 The parties shall endeavor to resolve their Claims by mediation which, unless the parties mutually agree
otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry
Mediation Procedures in effect on the date of the Agreement. A request for mediation shall be made in writing,
delivered to the other party to the Contract, and filed with the person or entity administering the mediation. The request
may be made concurrently with the filing of binding dispute resolution proceedings but, in such event, mediation shal
proceed in advance of binding dispute resolution proceedings, which shall be stayed pending mediation for a period of
60 days from the date of Filing, unless stayed for a longer period by agreement of the parties or court order. If an
arbitration is stayed pursuant to this Section 15.3.2, the parties may nonetheless proceed to the selection of the
arbitrator(s) and agree upon a schedule for later proceedings.
Init. AIA Doe nwot A201 "" — 2007, Copyright 0 1911, 1915. 1918, 1925, 1937, 1951, 1958. 1961. 1963. 1966. 1970. 1976. 1987. 1997 and 2007 by The American
Institute of Architects. All rights reserved. WARNING; This AIA111 document Is protected by U.S. Copyright Law and International Treaties. Unauthorized ?
reproduction or distribution of this AIA' Document, or any portion of it. may result In severe civil and criminal penalties. and will bo prosecuted to the
r maximum extent possible under the law_ This document was produced by AIA software at 15:04;44 on 06MY2014 under Order No 2801087948-1 wlkh expires
on 0912012014, and is not for resale.
User Notes: (1213612647)
§ 15.3.3 The parties shall share the mediator's fee and any filing fees equally. The mediation shall be held in the place
where the Project is located, unless another location is mutually agreed upon. Agreements reached in mediation shall
be enforceable as settlement agreements in any court having jurisdiction thereof.
§ 15.4 ARBITRATION
§ 15.4.1 If the parties have selected arbitration as the method for binding dispute resolution in the Agreement, any
Claim subject to, but not resolved by, mediation shall be subject to arbitration which, unless the parties mutually agree
otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry
Arbitration Rules in effect on the date of the Agreement. A demand for arbitration shall be made in writing, delivered
to the other party to the Contract, and Filed with the person or entity administering the arbitration. The party filing a
notice of demand for arbitration must assert in the demand all Claims then known to that party on which arbitration is
permitted to be demanded.
§ 15.4.1.1 A demand for arbitration shall be made no earlier than concurrently with the tiling of request for
mediation, but in no event shall it be made after the date when the institution of legal or equitable proceedings based on
the Claim would be barred by the applicable statute of limitations. For statute of limitations purposes, receipt of a
written demand for arbitration by the person or entity administering the arbitration shall constitute the institution of
legal or equitable proceedings based on the Claim.
§ 15.4.2 The award rendered by the arbitrator or arbitrators shall be final, and judgment may be entered upon it in
accordance with applicable law in any court having jurisdiction thereof.
§ 15.4.3 The foregoing agreement to arbitrate and other agreements to arbitrate with an additional person or entity duly
consented to by parties to the Agreement shall be specifically enforceable under applicable law ill any court having
jurisdiction thereof.
§ 15.4.4 CONSOLIDATION OR JOINDER
§ 15.4.4.1 Either party, at its sole discretion, may consolidate an arbitration conducted under this Agreement with any
other arbitration to which it is a party provided that (I ) the arbitration agreement governing the other arbitration
permits consolidation, (2) the arbitrations to be consolidated substantially involve common questions of law or fact,
and (3) the arbitrations employ materially similar procedural rules and methods for selecting arbitrator(s).
§ 15.4.4.2 father party, at its sole discretion, may include by joinder persons or entities substantially involved in a
common question of law or fact whose presence is required ifcomplete relief is to be accorded in arbitration, provided
that the party sought to be joined consents in writing to suchjoinder. Consent to arbitration involving an additional
person or entity shall not constitute consent to arbitration of any claim, dispute or other matter in question not
described in the written consent.
§ 15.4,4,3 The Owner and Contractor grant to any person or entity made a party to an arbitration conducted under this
Section 15.4. whether by joinder or consolidation, the same rights of joinder and consolidation as the Owner and
Contractor under this Agreement.
AIA 0"urhent A201111 —2007. Copyright 0 1911. 1915. 1910, 1925, 1937, 1951. 1958. 1961, 1963. 1966. 1970. 1976. 1987. 1997 and 2007 by The American
Init. Institute of Architects. All rights reserved. WARNING: This AIAa Document Is protected by U.S. Copyright Law and International Treatlos. llnauthorited
coproduction or distribution of this AIA°b document, or any portion of It, may result in severe civit and criminal penalties, and will be prosecuted to the
! maximum extent possible under the law. This document was produced by AIA software at 15:04.44 on OW1012014 under Order No.290108794q_1 which expires
on 09/2012014, and is not for resale.
User Notes: (1213t312647)