Loading...
HomeMy WebLinkAboutInfrastructure Contractors, Inc./UtilC?n_ r c 44 4? C)-,? o p AGREEMENT City of Carmel, jndians THIS AGREEMENT is made and entered into by and between the City of Carmel, Indiana, acting by and through its Board of Public Works and Safety ("OWNER") and Infrastructure Contractors. Inc. ("CONTRACTOR"), concerning the :project ("Project") described inore particularly in Appendix A which is, attached`hereto,and incorporated. herein by reference. RECITALS: A. The OWNER has heretofore caused to be prepared certain _plans, specifications and other documents (collectively; theContract >Documents") as hereinafter listed pertaining to the Project, and the. CONTRACTOR has filed a.bid.proposa3. (.'Proposal'•') to furnish labor, tools; material, equipment and/or .services,' and to Perform the-work ("Work") called for in the Contract Documents pertaining to the Project, upon the-terms and for the price(s) therein fully:stated and sct forth; and B. The said Contract Documents ?accuratelyand, fully describe the terms and conditions upon which the-CONTRACTOR is willing to 'furnish the. labor, tools; material, equipment, services, and perform the Work called for by the Contract Documents and in the manner and time and for the price(s) set forth therein. THE OWNER AND CONTRACTOR AGREE,AS FOLLOWS: 1.0 Contract Documents 1.1 This Agreement consists of the following Contract Docuients all of which are as fully a part of this Agreement as;if set-out verbatim -herein or,attached hereto-and the same do in all particulars become the Agreement between the parties hereto..in all matters and things set forth herein and described: a. This Agreement, including any attachments,hereto; b. All Addenda issued prior to receipt of'bid proposals, whether or not: receipt thereof has been acknowledged by CONTRACTOR in its Proposal; c_ The Spe6i fit cations; d. The Additional Requirements; e. Notice to Bidders; f. Instructions to Bidders; g. Plans and Drawings; h. Performance, Payment, and Maintenance Bonds; 1. CONTRACTOR'S Iternized'Proposal,and Dec1'arations; and A-i j. All other documents defined as Contract Documents in any of the above listed documents. 1.2 In resolving conflicts, errors, discrepancies and disputes' concerning the nature, character, scope and/or extent of Work to be-performed orlbrnished by the CONTRACTOR hereunder, or other rights and obligations of ther:OWNER and'/or CONTRACTOR, the provision of a Contract.Document expressing the greater quantity, quality or scope of the Work, or imposing a greater obligation upon the CONTRACTOR,.or affording a greater right or remedy to OWNER, shall govern, without regard to the party who drafted such provision; otherwise, the-Docunients shall be given precedence in the order as listed in paragraph l .l herein above. 2.0 Contract Price 2.1 The CONTRACTOR. shall, in strict, conformity with the•Contract Documents, furnish all necessary.] abor, tools, materials, equi pment,. services, assume and fulfill all obligations and perform all Work required to construct, complete, andrmake ready for use by the OWNER at the Unit, Prices .as quoted in the Proposal fora total contract price not to exceed S 154,413.00 Base Bid, subject to any additions or deletions based on actual approved quantities. of the respective unit price items, which price the CONTRACTOR agrees to accept as full payment for all such Work actually performed and accepted as described in the "Contract Items and Unit Prices specification" and other Contract Documents, (the "Contract Price':). The, CONTRACTOR agrees that each. unit price shall be--deemed full and complete compensation for all direct and indirect costs for the each respective item of Work,. including, without limitation, all materials, labor, supervision;, equipment, transportation, warranties, repairs, replacement, overhead and profit for the item, complete and in place. 2.2 The above stated Contract.Price will,be paid to the,CONTRACTOR in the manner and at such times:as set forth in the Contract Documents. 3.0 Contract Time ,& Liquidated Damages 3.I It is hereby understood and mutually agreed, by and between the CONTRACTOR, and OWNER, that the date of commencement and the time for completion of the Work as specified in4he,Contract"Documents are essential conditions of this Agreement. 3.2 The CONTRACTOR.agrees that the Work shall.he commenced no later than the date indicated. in the Notice to Proceed; to be provided, by OWNER to CONTRACTOR and that the Work shal`be.performed.regularly, diligently and without interruption at such a rate of progress as will insure 160% C'ornpletion of the Project„ including all main connections with perfonnanceptestiiig. and such remedial work as may be required by the OWNER, by the date specified in the Contract Documents. 33 Liquidated Damages. Owner and Contractor recognize that time is of the essence of the Agreement and that Owner will suffer. financial loss if the Work is not completed within the time specified in Paragraph 11. They also recognize the delays, expense and difficulties involved improving legal orArbitration proceednigs;the actual loss suffered by Owner if the Work is not completed on time. A`ceordinglyJnstead of requiring any such A-2 proof, Owner and Contractor agree that as liquidated damages for the delay (but not a penalty), Contractor shall pay Owner Five Hundred Dollars and No Cents ($500.00) per day for cach calendar day until the work is 100% Complete as specified in Paragraph 32. 3.4 The CONTRACTOR and OWNER acknowledge and agree that the time allotted by this Agreemenf:for the performance and completion of the Work'i's.reasonable and takes into account any and all `risks and adverse conditions which may befall the. CONTRACTOR hereunder 4. Effective Date This Agreement shall be deemed. effective as of the date and year on which the last of the parties hereto, or their representative: executes same, 5. Miscellaneous Provi'sioris 5.1 OWNER's Property Any and all documentation (other than, original tracings and original calculations) generated. by CONTRACTOR pursuant-to-this Agreement shall be-considered OWNER's exclusive property and shall'be-disclosed only to OWNER_ and'to.no other person without OWNER's prior express written consent. CONTRACTOR shall keep confidential all working and del iberative,ni ateri a] pursuant to, IC:644-3a4. 5.2 Termination Except as expressly stated to the contrary herein, this. Agreement may be suspended and/or terminated upon.such terms as are set forth in, Article 14 of the City of Carmel. Standard General Conditions, for Construction Contracts 2003 (the "General Conditions"), as incorporated herein by this reference. In the event any amount allegedly due hereunder °is dispu'te'd and such dispute is not resolved to OWNER's satisfaction within ten (10) business days after notice of such dispute is,given to CONTRACTOR„OWNER shall pay-such amount as'is in dispute, under protest, into 'the City Court of Carmel, which Court shall hold such money until notified of a resolution signed by both parties hereto or-until a final judgment is entered thereon. A-3 5.3 5.4 5.5 Binding Effect OWNER and CONTRACTOR and their respective officers, officials, partners, successors, executors, administrators, assigns and legal representatives are bound by this Agreement to the other party hereto and to, the officers, officials, partners, successors, executors; administrators, assigns and legal representatives of such other party in all respects: as to all covenants, agreements and obligations contained and/or incorporated herein. No Third Party Beneficiaries Nothing contained herein shall be construed to. give any rights or benefits Hereunder to anyone other than OWNER or CONTRACTOR, Relationship The relationship of the parties hereto shall be as provided for in this Agreement, and CONTRACTOR, as well as,its agents, employees,, contractors, subcontractors, outside sources and other persons shall in no fashion be, deemed to be an employee of OWNER. Furthermore. CONTRACTOR shall be solely responsible for payment. to or for its agents, employees, contractors;; subcontractors, outside sources. and, other persons all statutory, contractual and other compensation, benefits and obligationsAue thereto, and OWNER shall not be responsible for same. Rather, the Contract Price. to be paid hereunder by OWNER to CONTRACTOR shall, subject to the. terms and conditions hereof. be the full and maximum compensation and monies required of OWNER to be paid to CONTRACTOR pursuant to.this Agreement. 5.6 Insurance CONTRACTOR shall maintain.;such bonds and `insurance. as-_are set forth in Article5 of.the General-Conditions. 5.7 Indemnification CONTRACTOR shall indemnify and hold harmless OWNER, its officers, officials, employees, agents and legal representatives, from all losses, 'liabilities, claims, judgments-and liens; including; but not Tmited to, all costs, expenses and attorney fees, arising out of any intentional or 'negligent act of omission of CONTRACTOR and/or any of its, agents, employees; contractors, subcontractors, outside sources and/or other persons in the:perfonnance of_this .Agreement. The failure to do so shall constitute a material breach of this -Agreement, Thisjndemnification obligation shall. survive the termination of this,Agreement. A-4 5.8 5.9 5.10 5.11 Setoff In addition to any right,of setoff provided by law, all amounts due CONTRACTOR shall be considered net of indebtedness of CONTRACTOR to OWNER, and OWNER may deduct any amounts, due or to be come due:from CONTRACTOR to OWNER from any suers due.or to become due?firom OWNER to CONTRACTOR hereunder. Government Compliance CONTRACTOR agrees to complywith all present and -future federal, state and local taws, executive orders, rules, regulations, codes and ordinances which may be applicable to CONTRACTOR'S performance of its obligations under this Agreement, and all relevant provisions thereof are "incorpo"rated herein by this reference. CONTRACTOR agrees to indemnify, and hold harmless OWNER from any loss, damage or liability resulting from any violation of such laws, orders, rules, regulations; codes and/or ordinances.. This. indemnification obligation shall survive the termination of this Agreement. Severability. If any provision`of this Agreement is held to be invalid, illegal or unenforceable by a court of competent jurisdiction„ that provision shall be stricken, and all other provisions of this Agreement which can operate independently •of such stricken provision shall continue in full farce--and effect. Notice, Any notice, invoice, order or other correspondence required or permitted to be sent under or pursuant to this Agreement shall be in writing and either hand-delivered or sent by postage prepaid, U.S.. Certified mail,-return receipt requested, addressed to the parties at the following.address: OWNER: CONTRACTOR: City. of Carmel Board of Public Works and Safety One Civic Square Carmel, IN 46032 Attention: John Duffy; Manager Water and Wastewater Utilities' (with a copy to City Attorney, Department of Law; same address) lnfrastructure Contractors. Inc, 16100 Allisonville'Rd. Noblesville. In. 4606 Notwithstanding the above„ a Notice To Cease. All Workissued under or pursuit to Paragraph 5:2 hereinabove may be orally given, as.long,as such notice is thereafter followed' by written notice as provided in this Paragraph 5.11 within five (5) business days of the date of such oral,notice. A-5 5.12 Governing Law This Agreement shall be governed by and construed in accordance with the laws of the State of Indiana, except for its conflict of laws provisions; as well as with all municipal ordinances and codes of the City of Carmel. The parties further agree that, in the event a lawsuit is filed hereunder, they waive any rights to a jury trial they may have, agree to file any such lawsuit in an appropriate court in Hamilton County, Indiana only, and agree that such court is the appropriate venue for and has jurisdiction over same. 5.13 Waiver Any delay or partial inaction on the part of OWNER in exercising or pursuing any right and/or remedy provided hereunder or by law shall not operate to waive any such rights or remedies. 5.14 Exhibits All exhibits and/or appendices referenced herein, whether marked "Exhibit", "Appendix", or by some other title, shall be considered a part of this Agreement. 5.15 Prior Aereements This Agreement contains all of the agreements of the parties hereto with respect to the subject matter hereof, and supersedes all prior negotiations, representations, and/or contracts, either oral or written, respective thereto. 5.16 Representation and Warranties Each party hereto represents and warrants that it is authorized to enter into this Agreement and that such party, in executing this Agreement, has the authority to bind such party or the party which it represents, as the case may be. 5.17 Headings All headings and sections of this Agreement are inserted for convenience only and do not form a part of this Agreement nor limit, expand or otherwise alter the meaning of any provisions hereof. 5.18 Advice of Counsel The parties warrant that they have read this Agreement and understand it, are fully aware of their respective rights, have had the opportunity for the advice and assistance of an attorney throughout the negotiation of this Agreement, and enter into this Agreement freely, voluntarily and without any duress, undue influence, coercion or promise of benefit, except as expressly set forth herein. A-6 5.19 Entire Agreement This Agreement, together with any attachments hereto or referenced herein, constitutes the entire agreement between Vendor and City with respect to the subject matter hereof, and supersedes all prior oral or written representations and agreements regarding same. Notwithstanding any other term or condition set forth herein, but subject to paragraph 5.10 hereof, to the extent any term or condition contained in any exhibit attached to this Agreement conflicts with any term or condition contained in this Agreement, the term or condition contained in this Agreement shall govern and prevail, unless the parties hereto, or their successors in interest, expressly and in writing agree otherwise. This Agreement may only be modified by written amendment executed by both parties hereto, or their successors in interest. IN WITNESS WHEREOF, the parties hereto set their hand on the dates below written: OWNER: CITY OF CARMEL, INDIANA by and through its Board of Public Works and Safety BY: ?6? ames Brainard, Presiding Officer CONTRACTOR: B Date: -4, J 711- Mary Ann B rke, Member Date: f1 / - Lori Wat'semmber / Date: ?/0-6- ATTEST: yn?? ???, Clerk- easurer Diana Cordray P1 Title: General Manager Date: 3/ 1 1 /2008 Date: A-7 APPENDIX A PROJECT: Rosado Hill: Spring Mill Road & 106'h Street Water Main Extension WORK: As described by the Project plans and Contract Documents including, but not limited to: Water main installation along Spring Mill Road from north of Mill Ridge Drive to 106'h Street. Including the placement of approximately 975 LFT of horizontially directionally drilled 20" HDPE water main, approximately 35 LFT of open cut 8" D.I. water Hain, fittings, valves hydrants, water main connection, restoration & other related appurtenances. Close coordination with the anticipated residential development project in the same area will he required of the Contractor. DESIGN BY: CrossRoad Engineers, P.C. David F. Hammons 3417 S. Sherman Drive Beech Grove, IN 46107 Attn: Gregory J. Ilko, PE OWNER'S REPRESENTATIVE: John Duffy, Manager City of Carmel, Water and Wastewater Utilities 760 3`d Avenue SW; Suite 1 10 Carmel, IN 46032 A-8